MISSISSIPPI LEGISLATURE

2011 Regular Session

To: Education; Finance

By: Senator(s) Fillingane

Senate Bill 2234

AN ACT TO AUTHORIZE SCHOOL DISTRICTS TO ENTER INTO CAPITAL LEASES OF REAL OR PERSONAL PROPERTY FOR USE AS SCHOOL BUILDINGS OR SCHOOL FACILITIES; TO AUTHORIZE "BUILD-TO-SUIT" CAPITAL LEASES PROVIDING FOR THE CONSTRUCTION OF NEW SCHOOL FACILITIES OR THE RENOVATION OF EXISTING SCHOOL FACILITIES BY A PRIVATE DEVELOPER WITH CERTAIN GUARANTIES TO THE SCHOOL DISTRICT RELATED TO THE FACILITY THAT IS THE SUBJECT OF THE CAPITAL LEASE; TO PROVIDE CERTAIN REQUIREMENTS REGARDING SUCH CONSTRUCTION SERVICES; TO AUTHORIZE THE TRANSFER OF REAL ESTATE BY THE SCHOOL DISTRICT FOR SUCH CAPITAL LEASES; TO REQUIRE A LETTER OF CREDIT FOR SUCH CAPITAL LEASES; TO AMEND SECTION 37-7-355, MISSISSIPPI CODE OF 1972, IN CONFORMITY; TO AMEND SECTION 31-7-13, MISSISSIPPI CODE OF 1972, TO EXEMPT SCHOOL FACILITY CAPITAL LEASES FROM THE PUBLIC BID LAW REQUIREMENTS; AND FOR RELATED PURPOSES.

     BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF MISSISSIPPI:

     SECTION 1.  Capital leases of school buildings and school facilities.  (1)  Definitions.  The following definitions apply in this section:

          (a)  Capital lease.  A capital lease as defined by generally accepted accounting principles, regardless of how the parties describe the agreement.

          (b)  Private developer.  The entity with which the local school board enters into a capital lease or build-to-suit lease under the provisions of this section.

     (2)  Authorization.  Local school boards may enter into capital leases of real or personal property for use as school buildings or school facilities.  The capital lease may relate to an existing building or a new school building to be constructed.  The term of any capital lease, including any renewal periods, shall not exceed forty (40) years from the expected date that the local school board will take occupancy of the property that is the subject of a capital lease.

     (3)  Construction, repairs and renovation.  A capital lease entered into under this section may provide that the private developer is responsible for providing, or contracting for, construction, repair, or renovation work.  Construction, repair, or renovation work undertaken or contracted by a private developer is not subject to the requirements of Section 31-7-13.

     (4)  Nonsubstitution clause.  A capital lease may not contain a nonsubstitution clause that restricts the right of a local school board to continue to provide a service or activity or to replace or provide a substitute for any property financed or purchased by the capital lease.

     (5)  No deficiency judgment; no pledge of taxing power.  No deficiency judgment may be rendered against any local school board or any levying authority in any action for breach of a contractual obligation authorized by this section, and the taxing power of a school district is not and may not be pledged directly or indirectly to secure any monies due under a contract authorized by this section.  A capital lease shall state that it does not constitute a pledge of the taxing power or full faith and credit of the local school board or levying authority.

     (6)  Budgetary accounting.  A capital lease entered into under this section shall be considered a continuing contract for capital outlay.  Provided, however, in each fiscal year the appropriation of funds by the school district for the payment of amounts due under the capital lease shall be at the discretion of the school board.

     (7)  Local government approval.  Capital leases entered into under this section are subject to approval by the school district levying authority.

     (8)  No agreements on student assignment.  A capital lease may not contain any provision with respect to the assignment of specific students or students from a specific area to any specific school.

     (9)  Lien laws not affected.  Real property that is subject to a capital lease under this section is subject to liens and foreclosure actions in the same manner and to the same extent as if the property were owned in fee simple by a private entity.

     SECTION 2.  Build-to-suit capital leases.  (1)  Definitions.  For the purposes of this section, the following definitions apply:

          (a)  Build-to-suit capital lease.  A capital lease that provides for the construction of new facilities or the renovation of existing facilities by the private developer, the cost of which is estimated to be greater than Three Hundred Thousand Dollars ($300,000.00).

          (b)  Prime contractor.  A contractor who contracts directly with the private developer or the private developer's construction manager at risk, if any, for construction, repair, or renovation work under this section.

     (2)  Contract provisions.  A build-to-suit capital lease may include contractual provisions by the private developer regarding the provision of products, services, and guaranties related to a facility that is the subject of a capital lease.  A local school board may also enter into a separate agreement or series of related agreements regarding the provision of products, services, and guaranties related to a facility that is the subject of a capital lease; provided all agreements are approved by the levying authority in connection with the approval of the build-to-suit capital lease.

     (3)  Approval by local school board.  Before entering into a build-to-suit capital lease pursuant to this section, the local school board shall adopt a resolution as provided in this subsection.  Before adopting the resolution required by this subsection, the local school board shall publish a notice of its intent to enter into a build-to-suit capital lease at least ten (10) days in advance of the date of the meeting at which the action is contemplated and in a newspaper having general circulation within the geographic area served by the local school board.  The notice shall include, at a minimum, the date, time, and place of the meeting, a description in brief and general terms of the subject of the lease, the name of the other party to the lease, and an indication of the board's intent to take action to authorize the lease at the indicated meeting.  The resolution shall provide the following:

          (a)  That entering into the build-to-suit capital lease for one or more specified buildings or facilities is in the school district's best interests under all the circumstances.  In making this evaluation, the local school board may consider the time, cost, and quality of design, engineering, and construction, including the time required to begin and the time required to complete a particular activity; occupancy costs, including lease payments, life-cycle maintenance, repair, and energy costs; and any other factors the board deems relevant.

          (b)  That the private developer is qualified to provide, either alone or in conjunction with other identified and associated persons, the products and services called for under the proposed capital lease and any related agreements.  The local school board shall make this determination taking into account any factors the local school board deems relevant, including the knowledge, skill, and reputation of the provider and its associated persons, the goals and plans of providers for utilization of minority business enterprises, and the costs to be incurred by the local school board.

     (4)  Additional requirements regarding design services.  Required design and engineering services shall be performed by an engineer or a licensed architect.  All applicable requirements for the review or approval of design and specifications for school buildings by the State Department of Education and the Mississippi Department of Insurance apply to school buildings constructed, repaired, or renovated under a capital lease authorized under this section.

     (5)  Additional requirements regarding construction services.  A private developer is required to seek competition and minority business participation in connection with all construction work under this section in accordance with the following provisions:

          (a)  A private developer shall either (i) solicit bids from prime contractors for all construction work under this section, or (ii) select a construction manager at risk through a qualification-based process in which case the selected construction manager at risk shall solicit bids from all of its prime contractors for all construction work under this section.

          (b)  The private developer or its construction manager at risk may prequalify contractors.  The prequalification criteria, if any, shall be determined by the local school board and the private developer to address quality, performance, the time specified in the bids for performance of the contract, the cost of construction oversight, time for completion, capacity to perform, and other factors deemed appropriate by the private developer and the local school board.

          (c)  A private developer and its construction manager at risk, if any, shall comply with the requirements applicable to a public entity pursuant to Section 31-7-13(s), except the private developer and its construction manager at risk shall adopt the local school board's minority participation goal.  The local school board shall require the private developer to submit its plan for compliance and for approval by the local school board prior to the private developer soliciting bids under this subsection.

          (d)  A private developer or its construction manager at risk shall publicly advertise at least thirty (30) days in advance of the bid date in a newspaper having a general circulation within the geographic areas served by the local school board, shall open bids publicly, and shall award each contract to the lowest responsible, responsive and prequalified bidder, taking into consideration quality, performance, the time specified in the bids for performance of the contract, the cost of construction oversight, time for completion, and any other factors deemed appropriate by the private developer and the local school board and included in the bid solicitation.  A private developer or its construction manager at risk shall enter into the construction contracts directly with the successful bidder.  After the award of a contract or contracts, the private developer or its construction manager at risk and any contractor may negotiate and reach agreement with the successful bidder on modifications to all aspects of the contract, including the time for performance, the scope of the work, and the price to be paid.

          (e)  The local school board, in its discretion, may require the private developer to provide a performance and payment bond for construction work and may require the private developer to provide a bond or other appropriate guarantee to cover any other guarantees, products, or services to be provided by the private developer.

     (6)  Predevelopment agreements with private developer authorized.  Local school boards may enter into predevelopment agreements with a private developer in advance of entering into a build-to-suit capital lease.  Predevelopment agreements with private developers shall be approved by the school district levying authority.  Predevelopment agreements may include provisions for each of the following:

          (a)  Site selection, land acquisition, and site preparation, including such services as wetlands delineation, archaeological review, and state and local government land-use permitting.

          (b)  Building programming and design, including both architectural and engineering services pursuant to subsection (4) of this section.

     (7)  Real estate transfer authorized.  Notwithstanding any contrary provisions of law, the local school board may, pursuant to the procedures in Section 37-7-355, sell, lease, or otherwise transfer real or personal property to any private developer for construction, repair, or renovation of a school facility under a build-to-suit capital lease entered into pursuant to this section.  The conveying unit may subject the property to any covenants, conditions, or restrictions as the school district deems to be necessary to carry out the purposes of this section.

     (8)  Additional permitted lease terms.  In recognition of the potential economic and technical utility of build-to-suit capital leases, which include in their scope combinations of design, construction, operation, management, and maintenance responsibilities over prolonged periods of time, and the potential desirability of a single point of responsibility for these matters in connection with build-to-suit capital leases, any build-to-suit capital lease may include provisions imposing responsibility on the private developer or any identified affiliated entity for any of the following matters:

          (a)  Site selection, land acquisition, and site preparation, including wetlands delineation, archaeological review, and state and local government land-use permitting.

          (b)  Facility programming, planning, and design, including both architectural and engineering services.

          (c)  Qualification and prequalification of contractors and subcontractors.

          (d)  Construction and construction management.

          (e)  Financing.

          (f)  Facility maintenance and repairs.

          (g)  Energy usage guarantees.

          (h)  Transfer of ownership of the leased property to a local government entity at the end of the lease term.

          (i)  Any other guaranties, products, and services as the local school board may determine.

     (9)  Letter of credit.  A private developer shall provide an irrevocable letter of credit for the benefit of laborers and materialmen in an amount not less than five percent (5%) of the total cost of the improvements which are the subject of the build-to-suit capital lease and shall maintain the letter of credit throughout the construction of the project and for the succeeding six-month period.

     SECTION 3.  Section 37-7-355, Mississippi Code of 1972, is amended as follows:

     37-7-355.  (1)  Any school district by resolution of the school board is hereby empowered, without public or competitive bidding, to sell, lease, lend, grant or convey to a corporation, individual or partnership pursuant to Sections 37-7-351 through 37-7-359 or to permit such corporation, individual or partnership to use, maintain or operate as part of any public school facility, or to enter into build-to-suit capital leases with a private developer under the provisions of Sections 1 and 2 of this act, any real or personal property which may be necessary, useful or convenient for the purposes of the school district.  Any such conveyances may include sale-leaseback or lease-leaseback arrangements, without the necessity of complying with the requirements of Article 9 of Chapter 7 of Title 37, Mississippi Code of 1972, or any other general laws which might be applicable thereto, with regard to disposal of surplus property.  Any such sale, lease, loan, grant, conveyance or permit may be made or given with or without consideration and for a period of time not to exceed twenty (20) years for agreements entered into under any agreement and on any terms and conditions which may be approved by such school district.  Provided, however, that any such sale, lease, loan, grant, conveyance or permit executed under authority of this section shall provide that title to any real property transferred by a local school district shall revert to the school district at the expiration of the term.

     (2)  The resolution adopted by the school board or governing authority shall be published once each week for three (3) consecutive weeks in a newspaper having a general circulation in the school district involved, with the first publication thereof to be made not less than thirty (30) days prior to the date upon which the school board or governing authority is to take final action upon the question of sale, lease, loan, grant or conveyance to an authority.  If no petition requesting an election is filed prior to such meeting as hereinafter provided, then the school board or governing authority may, in its discretion, at said meeting, by resolution spread upon its minutes, give final approval to such sale, lease, loan, grant or conveyance.  If at any time prior to such meeting a petition signed by not less than twenty percent (20%) or fifteen hundred (1500), whichever is less, of the qualified electors of the school district involved shall be filed with the school board or governing authority requesting that an election be called on the question, then the school board or governing authority shall, not later than the next regular meeting, adopt a resolution calling an election to be held within such school district upon the question of authorizing such sale, lease, loan, grant or conveyance to an authority.  Such election shall be called and held, and notice thereof shall be given, in the same manner as for elections upon the question of issuing bonds of school districts, and the results thereof shall be certified to the school board or governing authority.  If at least three-fifths (3/5) of the qualified electors of the school district who voted in such election shall vote in favor of authorizing said action, then the school board or governing authority shall proceed to sell, lease, lend, grant or convey such property as prayed for in the original resolution of the school board or governing authority; however, unless at least three-fifths (3/5) of the qualified electors voting in an election vote in favor of such action, then no sale, lease, loan, grant or conveyance shall be made.

     SECTION 4.  Section 31-7-13, Mississippi Code of 1972, is amended as follows:

     31-7-13.  All agencies and governing authorities shall purchase their commodities and printing; contract for garbage collection or disposal; contract for solid waste collection or disposal; contract for sewage collection or disposal; contract for public construction; and contract for rentals as herein provided.

          (a)  Bidding procedure for purchases not over $5,000.00.  Purchases which do not involve an expenditure of more than Five Thousand Dollars ($5,000.00), exclusive of freight or shipping charges, may be made without advertising or otherwise requesting competitive bids.  However, nothing contained in this paragraph (a) shall be construed to prohibit any agency or governing authority from establishing procedures which require competitive bids on purchases of Five Thousand Dollars ($5,000.00) or less.

          (b)  Bidding procedure for purchases over $5,000.00 but not over $50,000.00.  Purchases which involve an expenditure of more than Five Thousand Dollars ($5,000.00) but not more than Fifty Thousand Dollars ($50,000.00), exclusive of freight and shipping charges may be made from the lowest and best bidder without publishing or posting advertisement for bids, provided at least two (2) competitive written bids have been obtained.  Any state agency or community/junior college purchasing commodities or procuring construction pursuant to this paragraph (b) may authorize its purchasing agent, or his designee, to accept the lowest competitive written bid under Fifty Thousand Dollars ($50,000.00).  Any governing authority purchasing commodities pursuant to this paragraph (b) may authorize its purchasing agent, or his designee, with regard to governing authorities other than counties, or its purchase clerk, or his designee, with regard to counties, to accept the lowest and best competitive written bid.  Such authorization shall be made in writing by the governing authority and shall be maintained on file in the primary office of the agency and recorded in the official minutes of the governing authority, as appropriate.  The purchasing agent or the purchase clerk, or their designee, as the case may be, and not the governing authority, shall be liable for any penalties and/or damages as may be imposed by law for any act or omission of the purchasing agent or purchase clerk, or their designee, constituting a violation of law in accepting any bid without approval by the governing authority.  The term "competitive written bid" shall mean a bid submitted on a bid form furnished by the buying agency or governing authority and signed by authorized personnel representing the vendor, or a bid submitted on a vendor's letterhead or identifiable bid form and signed by authorized personnel representing the vendor.  "Competitive" shall mean that the bids are developed based upon comparable identification of the needs and are developed independently and without knowledge of other bids or prospective bids.  Any bid item for construction in excess of Five Thousand Dollars ($5,000.00) shall be broken down by components to provide detail of component description and pricing.  These details shall be submitted with the written bids and become part of the bid evaluation criteria.  Bids may be submitted by facsimile, electronic mail or other generally accepted method of information distribution.  Bids submitted by electronic transmission shall not require the signature of the vendor's representative unless required by agencies or governing authorities.

          (c)  Bidding procedure for purchases over $50,000.00.

              (i)  Publication requirement.

                   1.  Purchases which involve an expenditure of more than Fifty Thousand Dollars ($50,000.00), exclusive of freight and shipping charges, may be made from the lowest and best bidder after advertising for competitive bids once each week for two (2) consecutive weeks in a regular newspaper published in the county or municipality in which such agency or governing authority is located.  However, all American Recovery and Reinvestment Act projects in excess of Twenty-five Thousand Dollars ($25,000.00) shall be bid.  All references to American Recovery and Reinvestment Act projects in this section shall not apply to programs identified in Division B of the American Recovery and Reinvestment Act.

                   2.  The purchasing entity may designate the method by which the bids will be received, including, but not limited to, bids sealed in an envelope, bids received electronically in a secure system, bids received via a reverse auction, or bids received by any other method that promotes open competition and has been approved by the Office of Purchasing and Travel.  The provisions of this item 2 of subparagraph (i) shall be repealed on July 1, 2011.

                   3.  The date as published for the bid opening shall not be less than seven (7) working days after the last published notice; however, if the purchase involves a construction project in which the estimated cost is in excess of Fifty Thousand Dollars ($50,000.00), such bids shall not be opened in less than fifteen (15) working days after the last notice is published and the notice for the purchase of such construction shall be published once each week for two (2) consecutive weeks.  However, all American Recovery and Reinvestment Act projects in excess of Twenty-five Thousand Dollars ($25,000.00) shall be bid.  For any projects in excess of Twenty-five Thousand Dollars ($25,000.00) under the American Recovery and Reinvestment Act, publication shall be made one (1) time and the bid opening for construction projects shall not be less than ten (10) working days after the date of the published notice.  The notice of intention to let contracts or purchase equipment shall state the time and place at which bids shall be received, list the contracts to be made or types of equipment or supplies to be purchased, and, if all plans and/or specifications are not published, refer to the plans and/or specifications on file.  If there is no newspaper published in the county or municipality, then such notice shall be given by posting same at the courthouse, or for municipalities at the city hall, and at two (2) other public places in the county or municipality, and also by publication once each week for two (2) consecutive weeks in some newspaper having a general circulation in the county or municipality in the above provided manner.  On the same date that the notice is submitted to the newspaper for publication, the agency or governing authority involved shall mail written notice to, or provide electronic notification to the main office of the Mississippi Procurement Technical Assistance Program under the Mississippi Development Authority that contains the same information as that in the published notice.  Submissions received by the Mississippi Procurement Technical Assistance Program for projects funded by the American Recovery and Reinvestment Act shall be displayed on a separate and unique Internet Web page accessible to the public and maintained by the Mississippi Development Authority for the Mississippi Procurement Technical Assistance Program.  Those American Recovery and Reinvestment Act related submissions shall be publicly posted within twenty-four (24) hours of receipt by the Mississippi Development Authority and the bid opening shall not occur until the submission has been posted for ten (10) consecutive days.  The Department of Finance and Administration shall maintain information regarding contracts and other expenditures from the American Recovery and Reinvestment Act, on a unique Internet Web page accessible to the public.  The Department of Finance and Administration shall promulgate rules regarding format, content and deadlines, unless otherwise specified by law, of the posting of award notices, contract execution and subsequent amendments, links to the contract documents, expenditures against the awarded contracts and general expenditures of funds from the American Recovery and Reinvestment Act.  Within one (1) working day of the contract award, the agency or governing authority shall post to the designated Web page maintained by the Department of Finance and Administration, notice of the award, including the award recipient, the contract amount, and a brief summary of the contract in accordance with rules promulgated by the department.  Within one (1) working day of the contract execution, the agency or governing authority shall post to the designated Web page maintained by the Department of Finance and Administration a summary of the executed contract and make a copy of the appropriately redacted contract documents available for linking to the designated Web page in accordance with the rules promulgated by the department.  The information provided by the agency or governing authority shall be posted to the Web page for the duration of the American Recovery and Reinvestment Act funding or until the project is completed, whichever is longer.

              (ii)  Bidding process amendment procedure.  If all plans and/or specifications are published in the notification, then the plans and/or specifications may not be amended.  If all plans and/or specifications are not published in the notification, then amendments to the plans/specifications, bid opening date, bid opening time and place may be made, provided that the agency or governing authority maintains a list of all prospective bidders who are known to have received a copy of the bid documents and all such prospective bidders are sent copies of all amendments.  This notification of amendments may be made via mail, facsimile, electronic mail or other generally accepted method of information distribution.  No addendum to bid specifications may be issued within two (2) working days of the time established for the receipt of bids unless such addendum also amends the bid opening to a date not less than five (5) working days after the date of the addendum.

              (iii)  Filing requirement.  In all cases involving governing authorities, before the notice shall be published or posted, the plans or specifications for the construction or equipment being sought shall be filed with the clerk of the board of the governing authority.  In addition to these requirements, a bid file shall be established which shall indicate those vendors to whom such solicitations and specifications were issued, and such file shall also contain such information as is pertinent to the bid.

              (iv)  Specification restrictions. 

                   1.  Specifications pertinent to such bidding shall be written so as not to exclude comparable equipment of domestic manufacture.  However, if valid justification is presented, the Department of Finance and Administration or the board of a governing authority may approve a request for specific equipment necessary to perform a specific job.  Further, such justification, when placed on the minutes of the board of a governing authority, may serve as authority for that governing authority to write specifications to require a specific item of equipment needed to perform a specific job.  In addition to these requirements, from and after July 1, 1990, vendors of relocatable classrooms and the specifications for the purchase of such relocatable classrooms published by local school boards shall meet all pertinent regulations of the State Board of Education, including prior approval of such bid by the State Department of Education.

                   2.  Specifications for construction projects may include an allowance for commodities, equipment, furniture, construction materials or systems in which prospective bidders are instructed to include in their bids specified amounts for such items so long as the allowance items are acquired by the vendor in a commercially reasonable manner and approved by the agency/governing authority.  Such acquisitions shall not be made to circumvent the public purchasing laws.

              (v)  Agencies and governing authorities may establish secure procedures by which bids may be submitted via electronic means.

          (d)  Lowest and best bid decision procedure.

              (i)  Decision procedure.  Purchases may be made from the lowest and best bidder.  In determining the lowest and best bid, freight and shipping charges shall be included.  Life-cycle costing, total cost bids, warranties, guaranteed buy-back provisions and other relevant provisions may be included in the best bid calculation.  All best bid procedures for state agencies must be in compliance with regulations established by the Department of Finance and Administration.  If any governing authority accepts a bid other than the lowest bid actually submitted, it shall place on its minutes detailed calculations and narrative summary showing that the accepted bid was determined to be the lowest and best bid, including the dollar amount of the accepted bid and the dollar amount of the lowest bid.  No agency or governing authority shall accept a bid based on items not included in the specifications.

              (ii)  Decision procedure for Certified Purchasing Offices.  In addition to the decision procedure set forth in paragraph (d)(i), Certified Purchasing Offices may also use the following procedure:  Purchases may be made from the bidder offering the best value.  In determining the best value bid, freight and shipping charges shall be included.  Life-cycle costing, total cost bids, warranties, guaranteed buy-back provisions, documented previous experience, training costs and other relevant provisions may be included in the best value calculation.  This provision shall authorize Certified Purchasing Offices to utilize a Request For Proposals (RFP) process when purchasing commodities.  All best value procedures for state agencies must be in compliance with regulations established by the Department of Finance and Administration.  No agency or governing authority shall accept a bid based on items or criteria not included in the specifications.

              (iii)  Construction project negotiations authority.  If the lowest and best bid is not more than ten percent (10%) above the amount of funds allocated for a public construction or renovation project, then the agency or governing authority shall be permitted to negotiate with the lowest bidder in order to enter into a contract for an amount not to exceed the funds allocated.

          (e)  Lease-purchase authorization.  For the purposes of this section, the term "equipment" shall mean equipment, furniture and, if applicable, associated software and other applicable direct costs associated with the acquisition.  Any lease-purchase of equipment which an agency is not required to lease-purchase under the master lease-purchase program pursuant to Section 31-7-10 and any lease-purchase of equipment which a governing authority elects to lease-purchase may be acquired by a lease-purchase agreement under this paragraph (e).  Lease-purchase financing may also be obtained from the vendor or from a third-party source after having solicited and obtained at least two (2) written competitive bids, as defined in paragraph (b) of this section, for such financing without advertising for such bids.  Solicitation for the bids for financing may occur before or after acceptance of bids for the purchase of such equipment or, where no such bids for purchase are required, at any time before the purchase thereof.  No such lease-purchase agreement shall be for an annual rate of interest which is greater than the overall maximum interest rate to maturity on general obligation indebtedness permitted under Section 75-17-101, and the term of such lease-purchase agreement shall not exceed the useful life of equipment covered thereby as determined according to the upper limit of the asset depreciation range (ADR) guidelines for the Class Life Asset Depreciation Range System established by the Internal Revenue Service pursuant to the United States Internal Revenue Code and regulations thereunder as in effect on December 31, 1980, or comparable depreciation guidelines with respect to any equipment not covered by ADR guidelines.  Any lease-purchase agreement entered into pursuant to this paragraph (e) may contain any of the terms and conditions which a master lease-purchase agreement may contain under the provisions of Section 31-7-10(5), and shall contain an annual allocation dependency clause substantially similar to that set forth in Section 31-7-10(8).  Each agency or governing authority entering into a lease-purchase transaction pursuant to this paragraph (e) shall maintain with respect to each such lease-purchase transaction the same information as required to be maintained by the Department of Finance and Administration pursuant to Section 31-7-10(13).  However, nothing contained in this section shall be construed to permit agencies to acquire items of equipment with a total acquisition cost in the aggregate of less than Ten Thousand Dollars ($10,000.00) by a single lease-purchase transaction.  All equipment, and the purchase thereof by any lessor, acquired by lease-purchase under this paragraph and all lease-purchase payments with respect thereto shall be exempt from all Mississippi sales, use and ad valorem taxes.  Interest paid on any lease-purchase agreement under this section shall be exempt from State of Mississippi income taxation.

          (f)  Alternate bid authorization.  When necessary to ensure ready availability of commodities for public works and the timely completion of public projects, no more than two (2) alternate bids may be accepted by a governing authority for commodities.  No purchases may be made through use of such alternate bids procedure unless the lowest and best bidder cannot deliver the commodities contained in his bid.  In that event, purchases of such commodities may be made from one (1) of the bidders whose bid was accepted as an alternate.

          (g)  Construction contract change authorization.  In the event a determination is made by an agency or governing authority after a construction contract is let that changes or modifications to the original contract are necessary or would better serve the purpose of the agency or the governing authority, such agency or governing authority may, in its discretion, order such changes pertaining to the construction that are necessary under the circumstances without the necessity of further public bids; provided that such change shall be made in a commercially reasonable manner and shall not be made to circumvent the public purchasing statutes.  In addition to any other authorized person, the architect or engineer hired by an agency or governing authority with respect to any public construction contract shall have the authority, when granted by an agency or governing authority, to authorize changes or modifications to the original contract without the necessity of prior approval of the agency or governing authority when any such change or modification is less than one percent (1%) of the total contract amount.  The agency or governing authority may limit the number, manner or frequency of such emergency changes or modifications.

          (h)  Petroleum purchase alternative.  In addition to other methods of purchasing authorized in this chapter, when any agency or governing authority shall have a need for gas, diesel fuel, oils and/or other petroleum products in excess of the amount set forth in paragraph (a) of this section, such agency or governing authority may purchase the commodity after having solicited and obtained at least two (2) competitive written bids, as defined in paragraph (b) of this section.  If two (2) competitive written bids are not obtained, the entity shall comply with the procedures set forth in paragraph (c) of this section.  In the event any agency or governing authority shall have advertised for bids for the purchase of gas, diesel fuel, oils and other petroleum products and coal and no acceptable bids can be obtained, such agency or governing authority is authorized and directed to enter into any negotiations necessary to secure the lowest and best contract available for the purchase of such commodities.

          (i)  Road construction petroleum products price adjustment clause authorization.  Any agency or governing authority authorized to enter into contracts for the construction, maintenance, surfacing or repair of highways, roads or streets, may include in its bid proposal and contract documents a price adjustment clause with relation to the cost to the contractor, including taxes, based upon an industry-wide cost index, of petroleum products including asphalt used in the performance or execution of the contract or in the production or manufacture of materials for use in such performance.  Such industry-wide index shall be established and published monthly by the Mississippi Department of Transportation with a copy thereof to be mailed, upon request, to the clerks of the governing authority of each municipality and the clerks of each board of supervisors throughout the state.  The price adjustment clause shall be based on the cost of such petroleum products only and shall not include any additional profit or overhead as part of the adjustment.  The bid proposals or document contract shall contain the basis and methods of adjusting unit prices for the change in the cost of such petroleum products.

          (j)  State agency emergency purchase procedure.  If the governing board or the executive head, or his designee, of any agency of the state shall determine that an emergency exists in regard to the purchase of any commodities or repair contracts, so that the delay incident to giving opportunity for competitive bidding would be detrimental to the interests of the state, then the provisions herein for competitive bidding shall not apply and the head of such agency shall be authorized to make the purchase or repair.  Total purchases so made shall only be for the purpose of meeting needs created by the emergency situation.  In the event such executive head is responsible to an agency board, at the meeting next following the emergency purchase, documentation of the purchase, including a description of the commodity purchased, the purchase price thereof and the nature of the emergency shall be presented to the board and placed on the minutes of the board of such agency.  The head of such agency, or his designee, shall, at the earliest possible date following such emergency purchase, file with the Department of Finance and Administration (i) a statement explaining the conditions and circumstances of the emergency, which shall include a detailed description of the events leading up to the situation and the negative impact to the entity if the purchase is made following the statutory requirements set forth in paragraph (a), (b) or (c) of this section, and (ii) a certified copy of the appropriate minutes of the board of such agency, if applicable.

          (k)  Governing authority emergency purchase procedure.  If the governing authority, or the governing authority acting through its designee, shall determine that an emergency exists in regard to the purchase of any commodities or repair contracts, so that the delay incident to giving opportunity for competitive bidding would be detrimental to the interest of the governing authority, then the provisions herein for competitive bidding shall not apply and any officer or agent of such governing authority having general or special authority therefor in making such purchase or repair shall approve the bill presented therefor, and he shall certify in writing thereon from whom such purchase was made, or with whom such a repair contract was made.  At the board meeting next following the emergency purchase or repair contract, documentation of the purchase or repair contract, including a description of the commodity purchased, the price thereof and the nature of the emergency shall be presented to the board and shall be placed on the minutes of the board of such governing authority.

          (l)  Hospital purchase, lease-purchase and lease authorization.

              (i)  The commissioners or board of trustees of any public hospital may contract with such lowest and best bidder for the purchase or lease-purchase of any commodity under a contract of purchase or lease-purchase agreement whose obligatory payment terms do not exceed five (5) years.

              (ii)  In addition to the authority granted in subparagraph (i) of this paragraph (l), the commissioners or board of trustees is authorized to enter into contracts for the lease of equipment or services, or both, which it considers necessary for the proper care of patients if, in its opinion, it is not financially feasible to purchase the necessary equipment or services.  Any such contract for the lease of equipment or services executed by the commissioners or board shall not exceed a maximum of five (5) years' duration and shall include a cancellation clause based on unavailability of funds.  If such cancellation clause is exercised, there shall be no further liability on the part of the lessee.  Any such contract for the lease of equipment or services executed on behalf of the commissioners or board that complies with the provisions of this subparagraph (ii) shall be excepted from the bid requirements set forth in this section.

          (m)  Exceptions from bidding requirements.  Excepted from bid requirements are:

              (i)  Purchasing agreements approved by department.  Purchasing agreements, contracts and maximum price regulations executed or approved by the Department of Finance and Administration.

              (ii)  Outside equipment repairs.  Repairs to equipment, when such repairs are made by repair facilities in the private sector; however, engines, transmissions, rear axles and/or other such components shall not be included in this exemption when replaced as a complete unit instead of being repaired and the need for such total component replacement is known before disassembly of the component; however, invoices identifying the equipment, specific repairs made, parts identified by number and name, supplies used in such repairs, and the number of hours of labor and costs therefor shall be required for the payment for such repairs.

              (iii)  In-house equipment repairs.  Purchases of parts for repairs to equipment, when such repairs are made by personnel of the agency or governing authority; however, entire assemblies, such as engines or transmissions, shall not be included in this exemption when the entire assembly is being replaced instead of being repaired.

              (iv)  Raw gravel or dirt.  Raw unprocessed deposits of gravel or fill dirt which are to be removed and transported by the purchaser.

              (v)  Governmental equipment auctions.  Motor vehicles or other equipment purchased from a federal agency or authority, another governing authority or state agency of the State of Mississippi, or any governing authority or state agency of another state at a public auction held for the purpose of disposing of such vehicles or other equipment.  Any purchase by a governing authority under the exemption authorized by this subparagraph (v) shall require advance authorization spread upon the minutes of the governing authority to include the listing of the item or items authorized to be purchased and the maximum bid authorized to be paid for each item or items.

              (vi)  Intergovernmental sales and transfers.  Purchases, sales, transfers or trades by governing authorities or state agencies when such purchases, sales, transfers or trades are made by a private treaty agreement or through means of negotiation, from any federal agency or authority, another governing authority or state agency of the State of Mississippi, or any state agency or governing authority of another state.  Nothing in this section shall permit such purchases through public auction except as provided for in subparagraph (v) of this section.  It is the intent of this section to allow governmental entities to dispose of and/or purchase commodities from other governmental entities at a price that is agreed to by both parties.  This shall allow for purchases and/or sales at prices which may be determined to be below the market value if the selling entity determines that the sale at below market value is in the best interest of the taxpayers of the state.  Governing authorities shall place the terms of the agreement and any justification on the minutes, and state agencies shall obtain approval from the Department of Finance and Administration, prior to releasing or taking possession of the commodities.

              (vii)  Perishable supplies or food.  Perishable supplies or food purchased for use in connection with hospitals, the school lunch programs, homemaking programs and for the feeding of county or municipal prisoners.

              (viii)  Single source items.  Noncompetitive items available from one (1) source only.  In connection with the purchase of noncompetitive items only available from one (1) source, a certification of the conditions and circumstances requiring the purchase shall be filed by the agency with the Department of Finance and Administration and by the governing authority with the board of the governing authority.  Upon receipt of that certification the Department of Finance and Administration or the board of the governing authority, as the case may be, may, in writing, authorize the purchase, which authority shall be noted on the minutes of the body at the next regular meeting thereafter.  In those situations, a governing authority is not required to obtain the approval of the Department of Finance and Administration.

              (ix)  Waste disposal facility construction contracts.  Construction of incinerators and other facilities for disposal of solid wastes in which products either generated therein, such as steam, or recovered therefrom, such as materials for recycling, are to be sold or otherwise disposed of; however, in constructing such facilities, a governing authority or agency shall publicly issue requests for proposals, advertised for in the same manner as provided herein for seeking bids for public construction projects, concerning the design, construction, ownership, operation and/or maintenance of such facilities, wherein such requests for proposals when issued shall contain terms and conditions relating to price, financial responsibility, technology, environmental compatibility, legal responsibilities and such other matters as are determined by the governing authority or agency to be appropriate for inclusion; and after responses to the request for proposals have been duly received, the governing authority or agency may select the most qualified proposal or proposals on the basis of price, technology and other relevant factors and from such proposals, but not limited to the terms thereof, negotiate and enter contracts with one or more of the persons or firms submitting proposals.

              (x)  Hospital group purchase contracts.  Supplies, commodities and equipment purchased by hospitals through group purchase programs pursuant to Section 31-7-38.

              (xi)  Information technology products.  Purchases of information technology products made by governing authorities under the provisions of purchase schedules, or contracts executed or approved by the Mississippi Department of Information Technology Services and designated for use by governing authorities.

              (xii)  Energy efficiency services and equipment.  Energy efficiency services and equipment acquired by school districts, community and junior colleges, institutions of higher learning and state agencies or other applicable governmental entities on a shared-savings, lease or lease-purchase basis pursuant to Section 31-7-14.

              (xiii)  Municipal electrical utility system fuel.  Purchases of coal and/or natural gas by municipally owned electric power generating systems that have the capacity to use both coal and natural gas for the generation of electric power.

              (xiv)  Library books and other reference materials.  Purchases by libraries or for libraries of books and periodicals; processed film, video cassette tapes, filmstrips and slides; recorded audio tapes, cassettes and diskettes; and any such items as would be used for teaching, research or other information distribution; however, equipment such as projectors, recorders, audio or video equipment, and monitor televisions are not exempt under this subparagraph.

              (xv)  Unmarked vehicles.  Purchases of unmarked vehicles when such purchases are made in accordance with purchasing regulations adopted by the Department of Finance and Administration pursuant to Section 31-7-9(2).

              (xvi)  Election ballots.  Purchases of ballots printed pursuant to Section 23-15-351.

              (xvii)  Multichannel interactive video systems.  From and after July 1, 1990, contracts by Mississippi Authority for Educational Television with any private educational institution or private nonprofit organization whose purposes are educational in regard to the construction, purchase, lease or lease-purchase of facilities and equipment and the employment of personnel for providing multichannel interactive video systems (ITSF) in the school districts of this state.

              (xviii)  Purchases of prison industry products.  From and after January 1, 1991, purchases made by state agencies  or governing authorities involving any item that is manufactured, processed, grown or produced from the state's prison industries.

              (xix)  Undercover operations equipment.  Purchases of surveillance equipment or any other high-tech equipment to be used by law enforcement agents in undercover operations, provided that any such purchase shall be in compliance with regulations established by the Department of Finance and Administration.

              (xx)  Junior college books for rent.  Purchases by community or junior colleges of textbooks which are obtained for the purpose of renting such books to students as part of a book service system.

              (xxi)  Certain school district purchases.  Purchases of commodities made by school districts from vendors with which any levying authority of the school district, as defined in Section 37-57-1, has contracted through competitive bidding procedures for purchases of the same commodities.

               (xxii)  Garbage, solid waste and sewage contracts.  Contracts for garbage collection or disposal, contracts for solid waste collection or disposal and contracts for sewage collection or disposal.

              (xxiii)  Municipal water tank maintenance contracts.  Professional maintenance program contracts for the repair or maintenance of municipal water tanks, which provide professional services needed to maintain municipal water storage tanks for a fixed annual fee for a duration of two (2) or more years.

              (xxiv)  Purchases of Mississippi Industries for the Blind products.  Purchases made by state agencies or governing authorities involving any item that is manufactured, processed or produced by the Mississippi Industries for the Blind.

              (xxv)  Purchases of state-adopted textbooks.  Purchases of state-adopted textbooks by public school districts.

              (xxvi)  Certain purchases under the Mississippi Major Economic Impact Act.  Contracts entered into pursuant to the provisions of Section 57-75-9(2), (3) and (4).

              (xxvii)  Used heavy or specialized machinery or equipment for installation of soil and water conservation practices purchased at auction.  Used heavy or specialized machinery or equipment used for the installation and implementation of soil and water conservation practices or measures purchased subject to the restrictions provided in Sections 69-27-331 through 69-27-341.  Any purchase by the State Soil and Water Conservation Commission under the exemption authorized by this subparagraph shall require advance authorization spread upon the minutes of the commission to include the listing of the item or items authorized to be purchased and the maximum bid authorized to be paid for each item or items.

              (xxviii)  Hospital lease of equipment or services.  Leases by hospitals of equipment or services if the leases are in compliance with paragraph (l)(ii).

              (xxix)  Purchases made pursuant to qualified cooperative purchasing agreements.  Purchases made by certified purchasing offices of state agencies or governing authorities under cooperative purchasing agreements previously approved by the Office of Purchasing and Travel and established by or for any municipality, county, parish or state government or the federal government, provided that the notification to potential contractors includes a clause that sets forth the availability of the cooperative purchasing agreement to other governmental entities.  Such purchases shall only be made if the use of the cooperative purchasing agreements is determined to be in the best interest of the governmental entity.

              (xxx)  School yearbooks.  Purchases of school yearbooks by state agencies or governing authorities; provided, however, that state agencies and governing authorities shall use for these purchases the RFP process as set forth in the Mississippi Procurement Manual adopted by the Office of Purchasing and Travel.

              (xxxi)  Design-build method and dual-phase design-build method of contracting.  Contracts entered into under the provisions of Section 31-7-13.1, 37-101-44 or 65-1-85.

              (xxxii)  Toll roads and bridge construction projects.  Contracts entered into under the provisions of Section 65-43-1 or 65-43-3.

              (xxxiii)  Certain purchases under Section 57-1-221.  Contracts entered into pursuant to the provisions of Section 57-1-221.

              (xxxiv)  Build-to-suit capital leases of school facilities with a private developer under the provisions of Sections 1 and 2 of this act.

          (n)  Term contract authorization.  All contracts for the purchase of:

              (i)  All contracts for the purchase of commodities, equipment and public construction (including, but not limited to, repair and maintenance), may be let for periods of not more than sixty (60) months in advance, subject to applicable statutory provisions prohibiting the letting of contracts during specified periods near the end of terms of office.  Term contracts for a period exceeding twenty-four (24) months shall also be subject to ratification or cancellation by governing authority boards taking office subsequent to the governing authority board entering the contract.

              (ii)  Bid proposals and contracts may include price adjustment clauses with relation to the cost to the contractor based upon a nationally published industry-wide or nationally published and recognized cost index.  The cost index used in a price adjustment clause shall be determined by the Department of Finance and Administration for the state agencies and by the governing board for governing authorities.  The bid proposal and contract documents utilizing a price adjustment clause shall contain the basis and method of adjusting unit prices for the change in the cost of such commodities, equipment and public construction.

          (o)  Purchase law violation prohibition and vendor penalty.  No contract or purchase as herein authorized shall be made for the purpose of circumventing the provisions of this section requiring competitive bids, nor shall it be lawful for any person or concern to submit individual invoices for amounts within those authorized for a contract or purchase where the actual value of the contract or commodity purchased exceeds the authorized amount and the invoices therefor are split so as to appear to be authorized as purchases for which competitive bids are not required.  Submission of such invoices shall constitute a misdemeanor punishable by a fine of not less than Five Hundred Dollars ($500.00) nor more than One Thousand Dollars ($1,000.00), or by imprisonment for thirty (30) days in the county jail, or both such fine and imprisonment.  In addition, the claim or claims submitted shall be forfeited.

          (p)  Electrical utility petroleum-based equipment purchase procedure.  When in response to a proper advertisement therefor, no bid firm as to price is submitted to an electric utility for power transformers, distribution transformers, power breakers, reclosers or other articles containing a petroleum product, the electric utility may accept the lowest and best bid therefor although the price is not firm.

          (q)  Fuel management system bidding procedure.  Any governing authority or agency of the state shall, before contracting for the services and products of a fuel management or fuel access system, enter into negotiations with not fewer than two (2) sellers of fuel management or fuel access systems for competitive written bids to provide the services and products for the systems.  In the event that the governing authority or agency cannot locate two (2) sellers of such systems or cannot obtain bids from two (2) sellers of such systems, it shall show proof that it made a diligent, good-faith effort to locate and negotiate with two (2) sellers of such systems.  Such proof shall include, but not be limited to, publications of a request for proposals and letters soliciting negotiations and bids.  For purposes of this paragraph (q), a fuel management or fuel access system is an automated system of acquiring fuel for vehicles as well as management reports detailing fuel use by vehicles and drivers, and the term "competitive written bid" shall have the meaning as defined in paragraph (b) of this section.  Governing authorities and agencies shall be exempt from this process when contracting for the services and products of fuel management or fuel access systems under the terms of a state contract established by the Office of Purchasing and Travel.

          (r)  Solid waste contract proposal procedure.  Before entering into any contract for garbage collection or disposal, contract for solid waste collection or disposal or contract for sewage collection or disposal, which involves an expenditure of more than Fifty Thousand Dollars ($50,000.00), a governing authority or agency shall issue publicly a request for proposals concerning the specifications for such services which shall be advertised for in the same manner as provided in this section for seeking bids for purchases which involve an expenditure of more than the amount provided in paragraph (c) of this section.  Any request for proposals when issued shall contain terms and conditions relating to price, financial responsibility, technology, legal responsibilities and other relevant factors as are determined by the governing authority or agency to be appropriate for inclusion; all factors determined relevant by the governing authority or agency or required by this paragraph (r) shall be duly included in the advertisement to elicit proposals.  After responses to the request for proposals have been duly received, the governing authority or agency shall select the most qualified proposal or proposals on the basis of price, technology and other relevant factors and from such proposals, but not limited to the terms thereof, negotiate and enter into contracts with one or more of the persons or firms submitting proposals.  If the governing authority or agency deems none of the proposals to be qualified or otherwise acceptable, the request for proposals process may be reinitiated.  Notwithstanding any other provisions of this paragraph, where a county with at least thirty-five thousand (35,000) nor more than forty thousand (40,000) population, according to the 1990 federal decennial census, owns or operates a solid waste landfill, the governing authorities of any other county or municipality may contract with the governing authorities of the county owning or operating the landfill, pursuant to a resolution duly adopted and spread upon the minutes of each governing authority involved, for garbage or solid waste collection or disposal services through contract negotiations.

          (s)  Minority set-aside authorization.  Notwithstanding any provision of this section to the contrary, any agency or governing authority, by order placed on its minutes, may, in its discretion, set aside not more than twenty percent (20%) of its anticipated annual expenditures for the purchase of commodities from minority businesses; however, all such set-aside purchases shall comply with all purchasing regulations promulgated by the Department of Finance and Administration and shall be subject to bid requirements under this section.  Set-aside purchases for which competitive bids are required shall be made from the lowest and best minority business bidder.  For the purposes of this paragraph, the term "minority business" means a business which is owned by a majority of persons who are United States citizens or permanent resident aliens (as defined by the Immigration and Naturalization Service) of the United States, and who are Asian, Black, Hispanic or Native American, according to the following definitions:

              (i)  "Asian" means persons having origins in any of the original people of the Far East, Southeast Asia, the Indian subcontinent, or the Pacific Islands.

              (ii)  "Black" means persons having origins in any black racial group of Africa.

              (iii)  "Hispanic" means persons of Spanish or Portuguese culture with origins in Mexico, South or Central America, or the Caribbean Islands, regardless of race.

              (iv)  "Native American" means persons having origins in any of the original people of North America, including American Indians, Eskimos and Aleuts.

          (t)  Construction punch list restriction.  The architect, engineer or other representative designated by the agency or governing authority that is contracting for public construction or renovation may prepare and submit to the contractor only one (1) preliminary punch list of items that do not meet the contract requirements at the time of substantial completion and one (1) final list immediately before final completion and final payment.

          (u)  Procurement of construction services by state institutions of higher learning.  Contracts for privately financed construction of auxiliary facilities on the campus of a state institution of higher learning may be awarded by the Board of Trustees of State Institutions of Higher Learning to the lowest and best bidder, where sealed bids are solicited, or to the offeror whose proposal is determined to represent the best value to the citizens of the State of Mississippi, where requests for proposals are solicited.

          (v)  Insurability of bidders for public construction or other public contracts.  In any solicitation for bids to perform public construction or other public contracts to which this section applies including, but not limited to, contracts for repair and maintenance, for which the contract will require insurance coverage in an amount of not less than One Million Dollars ($1,000,000.00), bidders shall be permitted to either submit proof of current insurance coverage in the specified amount or demonstrate ability to obtain the required coverage amount of insurance if the contract is awarded to the bidder.  Proof of insurance coverage shall be submitted within five (5) business days from bid acceptance.

          (w)  Purchase authorization clarification.  Nothing in this section shall be construed as authorizing any purchase not authorized by law.

     SECTION 5.  This act shall take effect and be in force from and after July 1, 2011.