MISSISSIPPI LEGISLATURE
2021 Regular Session
To: Ways and Means
By: Representative Lamar
AN ACT TO AMEND SECTION 31-7-13.1, MISSISSIPPI CODE OF 1972, TO REVISE THE DUAL-PHASE DESIGN-BUILD METHOD OF CONSTRUCTION CONTRACTING; TO REMOVE THE REQUIREMENT FOR TWO PHASES OF DESIGN-BUILD CONSTRUCTION CONTRACTING; TO PROVIDE THAT DESIGN-BUILD CONSTRUCTION CONTRACTING MAY BE USED FOR RESIDENTIAL BUILDINGS, RESIDENTIAL-MIXED USED DEVELOPMENTS, PARKING GARAGES AND OTHER PRESCRIPTIVE TYPE FACILITIES; TO PROVIDE THAT THE DESIGN-BUILD METHOD OF CONSTRUCTION CONTRACTING MAY ONLY BE USED WHEN THE DEPARTMENT OF FINANCE AND ADMINISTRATION OR A GOVERNING AUTHORITY HAS DETERMINED THAT USING THE DESIGN-BUILD METHOD OF CONSTRUCTION CONTRACTING SATISFIES THE PUBLIC INTEREST BETTER THAN TRADITIONAL DESIGN BID OR WHEN THE LEGISLATURE HAS SPECIFICALLY REQUIRED OR AUTHORIZED THE USE OF THIS METHOD IN THE LEGISLATION AUTHORIZING A PROJECT; TO PROVIDE THAT INSTEAD OF THE DUAL-PHASE PROCEDURE FOR AWARDING A CONTRACT, FOR EACH PROPOSED DESIGN-BUILD PROJECT, EITHER A FIXED FIRM PRICE OR GUARANTEED MAXIMUM PRICE CONTRACT MUST BE ADOPTED; TO REVISE WHAT MUST BE INCLUDED IN THE WORK STATEMENT; TO PROVIDE THAT NOTICE SHALL ALSO BE POSTED ON THE MISSISSIPPI PROCUREMENT PORTAL; TO PROVIDE THAT PROPOSALS WHICH INCLUDE CRITERIA OTHER THAN COST ONLY SHALL BE EVALUATED BY AN EVALUATION COMMITTEE ESTABLISHED BY THE PROCURING ENTITY; TO PROVIDE THE MAKEUP OF THE EVALUATION COMMITTEE AND THE SELECTION CRITERIA THAT THE EVALUATION COMMITTEE SHALL CONSIDER WHEN EVALUATING SUBMITTED PROPOSALS; TO PROVIDE THAT AN AGENCY OR GOVERNING AUTHORITY MAY NOT AWARD A STIPULATED FEE TO AN OFFEROR FOR PREPARATION COSTS TO SUBMIT A RESPONSE TO THE REQUEST FOR PROPOSALS; TO AMEND SECTIONS 31-11-3, 61-3-15 AND 31-7-13, MISSISSIPPI CODE OF 1972, TO CONFORM TO THE PRECEDING SECTION; AND FOR RELATED PURPOSES.
BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF MISSISSIPPI:
SECTION 1. Section 31-7-13.1, Mississippi Code of 1972, is amended as follows:
31-7-13.1. (1) The method
of contracting for construction described in this section shall be known as the
" * * *
design-build method" of construction contracting. This method of
construction contracting may be used * * * on residential buildings, residential
mixed-use developments, parking garages and other prescriptive type
facilities. The design-build method of construction contracting may only be
used when the Department of Finance and Administration or a governing authority
has determined that it satisfies the public interest better than traditional
design-bid or when the Legislature has specifically required or authorized
the use of this method in the legislation authorizing a project. At a minimum,
the determination must include a detailed explanation of why using the * * * design-build method for a
particular project satisfies the public need better than the traditional design-bid-build
method based on the following criteria:
(a) The project provides a savings in time or cost over traditional methods; and
(b) The size and type of the project is suitable for design-build.
(2) For each proposed * * * design-build project, either
a * * * fixed firm price or guaranteed maximum
price contract must be adopted. * * * Before solicitation of * * * proposals, the agency or governing
authority shall develop * * *, with the assistance of an architectural or engineering firm,
a scope of work statement that provides prospective offerors with sufficient
information regarding the requirements of the agency or governing authority.
The scope of work statement must include, but is not limited to, the following
information:
(a) * * * Location and nature of
proposed site(s) that include preliminary geotechnical information from borings
as well as survey drawings that show topography, adjacent buildings and
utilities;
(b) * * * Any mandatory
requirements such as minimum number and types of spaces, any minimum or maximum
building area(s) or height(s), applicable energy codes and/or efficiency
targets, applicable zoning regulations and any aesthetic or character defining
standards;
(c) * * * Any mandatory material
and/or system performance requirements and/or specifications; and
(d) * * *
General budget parameters, schedule or delivery requirements, relevant criteria
for evaluation of proposals, and any other information necessary to enable the
design-builders to submit proposals that meet the needs of the agency or
governing authority.
(3) The agency or governing
authority shall cause to be published once a week, for at least two (2)
consecutive weeks in a regular newspaper published in the county in which the
project is to be located, or a newspaper with statewide circulation, a notice
inviting proposals for the * * * design-build construction
project. On the same date that the notice is submitted to the newspaper for
publication, the agency or governing authority involved shall post the notice
on the Mississippi Procurement Portal or mail written notice to, or provide
electronic notification to, the main office of the Mississippi Procurement
Technical Assistance Program under the Mississippi Development Authority that
contains the same information as that in the published notice. The proposals
shall not be opened in less than fifteen (15) working days after the last
notice is published. The notice must inform potential offerors of how to
obtain the scope of work statement developed for the project, and the notice
must contain such other information to describe adequately the general nature
and scope of the project so as to promote full, equal and open competition.
(4) The agency or governing
authority shall accept initial proposals only from entities able to provide an
experienced and qualified design-build team that includes, at a minimum, an
architectural or engineering firm licensed and registered in Mississippi
and a contractor properly licensed and domiciled in Mississippi for the type of
work required. * * *
(5) * * * Proposals that include
criteria other than cost only shall be evaluated by an evaluation committee
established by the procuring entity. The evaluation committee shall be
composed of not less than three (3) people, at least one (1) of which shall be
an architect or engineer licensed and registered in Mississippi. Selection
criteria of the evaluation committee shall be limited to the following:
(a) The bidder's knowledge and experience in executing projects of similar size and complexity;
(b) The experience and qualifications of the proposed office and construction management personnel;
(c) The experience and qualifications of the subcontractors proposed;
(d) The experience and qualifications of the architect or engineer and consultants;
(e) Schedule control; and
(f) Cost factors.
Cost as an evaluation factor shall be given the highest criteria weighting and at least thirty-five percent (35%) out of the one hundred percent (100%) total weight of all the other evaluation factors.
(6) If the agency or
governing authority accepts a proposal other than the * * * proposal with the lowest costs
that was actually submitted, the agency or governing authority shall enter
on its minutes detailed calculations and a narrative summary showing why the
accepted proposal was determined to provide the best value, and the agency or
governing authority shall state specifically on its minutes the justification
for its award.
(7) All facilities that are governed by this section shall be designed and constructed to comply with standards equal to or exceeding the minimum building code standards employed by the state as required under Section 31-11-33 in force at the time of contracting. All private contractors or private entities contracting or performing under this section must comply at all times with all applicable laws, codes and other legal requirements pertaining to the project.
(8) * * * An agency or
governing authority may not award a stipulated fee * * * to an offeror for
preparation costs to submit a response to the request for proposals.
(9) This section shall not authorize the awarding of construction contracts according to any contracting method that does not require the contractor to satisfactorily perform, at a minimum, both any balance of design, using an independent professional licensed in Mississippi, and construction of the project for which the contract is awarded.
(10) The provisions of this section shall not affect any procurement by the Mississippi Transportation Commission.
(11) The provisions of this section shall not apply to procurement authorized in Section 59-5-37(3).
SECTION 2. Section 31-11-3, Mississippi Code of 1972, is amended as follows:
31-11-3. (1) The Department of Finance and Administration, for the purposes of carrying out the provisions of this chapter, in addition to all other rights and powers granted by law, shall have full power and authority to employ and compensate architects or other employees necessary for the purpose of making inspections, preparing plans and specifications, supervising the erection of any buildings, and making any repairs or additions as may be determined by the Department of Finance and Administration to be necessary, pursuant to the rules and regulations of the State Personnel Board. The department shall have entire control and supervision of, and determine what, if any, buildings, additions, repairs, demolitions or improvements are to be made under the provisions of this chapter, subject to the regulations adopted by the Public Procurement Review Board.
(2) The department shall have full power to erect buildings, make repairs, additions or improvements, demolitions, to grant or acquire easements or rights-of-way, and to buy materials, supplies and equipment for any of the institutions or departments of the state subject to the regulations adopted by the Public Procurement Review Board. In addition to other powers conferred, the department shall have full power and authority, as directed by the Legislature, or when funds have been appropriated for its use for these purposes, to:
(a) Build a state office building;
(b) Build suitable plants or buildings for the use and housing of any state schools or institutions, including the building of plants or buildings for new state schools or institutions, as provided for by the Legislature;
(c) Provide state aid for the construction of school buildings;
(d) Promote and develop the training of returned veterans of the United States in all sorts of educational and vocational learning to be supplied by the proper educational institution of the State of Mississippi, and in so doing allocate monies appropriated to it for these purposes to the Governor for use by him in setting up, maintaining and operating an office and employing a state director of on-the-job training for veterans and the personnel necessary in carrying out Public Law No. 346 of the United States;
(e) Build and equip a hospital and administration building at the Mississippi State Penitentiary;
(f) Build and equip additional buildings and wards at the Boswell Retardation Center;
(g) Construct a sewage disposal and treatment plant at the Mississippi State Hospital, and in so doing acquire additional land as may be necessary, and to exercise the right of eminent domain in the acquisition of this land;
(h) Build and equip the Mississippi central market and purchase or acquire by eminent domain, if necessary, any lands needed for this purpose;
(i) Build and equip suitable facilities for a training and employing center for the blind;
(j) Build and equip a gymnasium at Columbia Training School;
(k) Approve or disapprove the expenditure of any money appropriated by the Legislature when authorized by the bill making the appropriation;
(l) Expend monies appropriated to it in paying the state's part of the cost of any street paving;
(m) Sell and convey state lands when authorized by the Legislature, cause said lands to be properly surveyed and platted, execute all deeds or other legal instruments, and do any and all other things required to effectively carry out the purpose and intent of the Legislature. Any transaction which involves state lands under the provisions of this paragraph shall be done in a manner consistent with the provisions of Section 29-1-1;
(n) Collect and receive from educational institutions of the State of Mississippi monies required to be paid by these institutions to the state in carrying out any veterans' educational programs;
(o) Purchase lands for building sites, or as additions to building sites, for the erection of buildings and other facilities which the department is authorized to erect, and demolish and dispose of old buildings, when necessary for the proper construction of new buildings. Any transaction which involves state lands under the provisions of this paragraph shall be done in a manner consistent with the provisions of Section 29-1-1;
(p) Obtain business property insurance with a deductible of not less than One Hundred Thousand Dollars ($100,000.00) on state-owned buildings under the management and control of the department; and
(q) In consultation with and approval by the Chairmen of the Public Property Committees of the Senate and the House of Representatives, enter into contracts for the purpose of providing parking spaces for state employees who work in the Woolfolk Building, the Carroll Gartin Justice Building or the Walter Sillers Office Building.
(3) The department shall survey state-owned and state-utilized buildings to establish an estimate of the costs of architectural alterations, pursuant to the Americans With Disabilities Act of 1990, 42 USCS, Section 12111 et seq. The department shall establish priorities for making the identified architectural alterations and shall make known to the Legislative Budget Office and to the Legislature the required cost to effectuate such alterations. To meet the requirements of this section, the department shall use standards of accessibility that are at least as stringent as any applicable federal requirements and may consider:
(a) Federal minimum guidelines and requirements issued by the United States Architectural and Transportation Barriers Compliance Board and standards issued by other federal agencies;
(b) The criteria contained in the American Standard Specifications for Making Buildings Accessible and Usable by the Physically Handicapped and any amendments thereto as approved by the American Standards Association, Incorporated (ANSI Standards);
(c) Design manuals;
(d) Applicable federal guidelines;
(e) Current literature in the field;
(f) Applicable safety standards; and
(g) Any applicable environmental impact statements.
(4) The department shall observe the provisions of Section 31-5-23 in letting contracts and shall use Mississippi products, including paint, varnish and lacquer which contain as vehicles tung oil and either ester gum or modified resin (with rosin as the principal base of constituents), and turpentine shall be used as a solvent or thinner, where these products are available at a cost not to exceed the cost of products grown, produced, prepared, made or manufactured outside of the State of Mississippi.
(5) The department shall have authority to accept grants, loans or donations from the United States government or from any other sources for the purpose of matching funds in carrying out the provisions of this chapter.
(6) The department shall build a wheelchair ramp at the War Memorial Building which complies with all applicable federal laws, regulations and specifications regarding wheelchair ramps.
(7) The department shall review and preapprove all architectural or engineering service contracts entered into by any state agency, institution, commission, board or authority, regardless of the source of funding used to defray the costs of the construction or renovation project, for which services are to be obtained to ensure compliance with purchasing regulations and to confirm that the contracts are procured by a competitive qualification-based selection process except where such appointment is for an emergency project or for a continuation of a previous appointment for a directly related project. The provisions of this subsection (7) shall not apply to:
(a) Any architectural or engineering contract fully paid for by self-generated funds of any of the state institutions of higher learning;
(b) Any architectural or engineering contract that is self-administered at a state institution of higher learning as provided under Section 27-104-7(2)(b) or 37-101-15(m);
(c) Community college projects that are fully funded from local funds or other nonstate sources which are outside the Department of Finance and Administration's appropriations or as directed by the Legislature;
(d) Any construction or design projects of the State Military Department that are fully or partially funded from federal funds or other nonstate sources; and
(e) Any project of the State Department of Transportation.
(8) (a) The department shall have the authority to obtain annually from the state institutions of higher learning, the state community colleges and junior colleges, the Department of Mental Health, the Department of Corrections and the Department of Wildlife, Fisheries and Parks information on all renovation and repair expenditures for buildings under their operation and control, including duties, responsibilities and costs of any architect or engineer hired by any such institutions, and shall annually report the same to the Legislative Budget Office, the Chairman of the House Public Property Committee and the Chairman of the Senate Public Property Committee before September 1.
(b) All state agencies, departments and institutions are required to cooperate with the Department of Finance and Administration in carrying out the provisions of this subsection.
(c) Expenditures shall not include those amounts expended for janitorial, landscaping or administrative support, but shall include expenditures from both state and nonstate sources.
(d) Expenditures shall not include amounts expended by the department on behalf of state agencies, departments and institutions through the Department of Finance and Administration administered contracts, but shall include amounts transferred to the Department of Finance and Administration for support of such contracts.
(9) As an alternative to
other methods of awarding contracts as prescribed by law, the department may
elect to use the method of contracting for construction projects set out in
Sections 31-7-13.1 and 31-7-13.2; however, the * * * design-build method of
construction contracting authorized under Section 31-7-13.1 may be used only
when the Legislature has specifically required or authorized the use of this
method in the legislation authorizing a project.
(10) The department shall have the authority, for the purposes of carrying out the provisions of this chapter, and in addition to all other rights and powers granted by law, to create and maintain a list of suspended and debarred contractors and subcontractors. Consistent with this authority, the department may adopt regulations governing the suspension or debarment of contractors and subcontractors, which regulations shall be subject to the approval of the Public Procurement Review Board. A suspended or debarred contractor or subcontractor shall be disqualified from consideration for contracts with the department during the suspension or debarment period in accordance with the department's regulations.
(11) This section shall not apply to the Mississippi State Port Authority.
SECTION 3. Section 61-3-15, Mississippi Code of 1972, is amended as follows:
61-3-15. An authority shall have all the powers necessary or convenient to carry out the purposes of this chapter (excluding the power to levy and collect taxes or special assessments) including, but not limited to, the power:
(a) To sue and be sued, to have a seal and to have perpetual succession.
(b) To purchase general liability insurance coverage, including errors and omissions insurance, for its officials and employees.
(c) To employ an executive director, secretary, technical experts, and such other officers, agents and employees, permanent and temporary, as it may require, and to determine their qualifications and duties, and to establish compensation and other employment benefits as may be advisable to attract and retain proficient personnel.
(d) To execute such contracts and other instruments and take such other action as may be necessary or convenient to carry out the purposes of this chapter.
(e) To plan, establish,
develop, construct, enlarge, improve, maintain, equip, operate, regulate and
protect airports and air navigation facilities within this state and within any
adjoining state, including the acquisition, lease, lease-purchase,
construction, installation, equipment, maintenance and operation of such
airports or buildings, equipment and other facilities or other property for the
servicing of aircraft or for the comfort and accommodation of air travelers or
for any other purpose deemed by the authority to be necessary to carry out its
duties; to develop, operate, manage or own and maintain intermodal facilities
to serve air and surface cargo and multimodal facilities to serve highway and
rail passenger transportation needs to ensure interface and interaction between
modes for cargo and passengers; to construct, improve, and maintain means of
ingress and egress to airport properties from and over off-airport sites with
approval of the city or county in which the off-airport site is located; to
market, promote and advertise airport properties, goods and services; and to
directly purchase and sell supplies, goods and commodities incident to the
operation of its airport properties without having to make purchases thereof
through the municipal governing authorities, and with the authority to utilize * * * design-build and construction
manager at-risk methods of construction in accordance with Sections 31-7-13.1
and 31-7-13.2. For all the previously stated purposes, an authority may, by
purchase, gift, devise, lease, eminent domain proceedings or otherwise, acquire
property, real or personal, or any interest therein, including easements in
airport hazards or land outside the boundaries of an airport or airport site,
as are necessary to permit the removal, elimination, obstruction-marking or
obstruction-lighting of airport hazards, to prevent the establishment of
airport hazards or to carry out its duties.
(f) To acquire, by purchase, gift, devise, lease, lease-purchase, eminent domain proceedings or otherwise, existing airports and air navigation facilities. However, an authority shall not acquire or take over any airport or air navigation facility owned or controlled by another authority, a municipality or public agency of this or any other state without the consent of such authority, municipality or public agency.
(g) To establish or acquire and maintain airports in, over and upon any public waters of this state, and any submerged lands under such public waters, and to construct and maintain terminal buildings, landing floats, causeways, roadways and bridges for approaches to or connecting with any such airport, and landing floats and breakwaters for the protection thereof.
(h) To establish, enact and enforce ordinances, rules, regulations and standards for public safety, aviation safety, airport operations and the preservation of good order and peace of the authority; to prevent injury to, destruction of or interference with public or private property; to protect property, health and lives and to enhance the general welfare of the authority by restricting the movements of citizens or any group thereof on the property of the authority when there is imminent danger to the public safety because of freedom of movement thereof; to regulate the entrances to property and buildings of the authority and the way of ingress and egress to and from the same; to establish fire limits and to hire firemen, including aircraft fire and rescue and similar personnel, and to establish and equip a fire department to provide fire and other emergency services on any property of the authority; to regulate, restrain or prohibit construction failing to meet standards established by the authority; to appoint and discharge police officers with jurisdiction limited to property of the airport authority and authorization to enforce the ordinances, rules and regulations of the authority, as well as the laws of the State of Mississippi, and to issue citations for infractions of all of such ordinances, rules, regulations, standards and laws of the State of Mississippi returnable to the court of appropriate jurisdiction.
(i) To develop and operate an industrial park or parks and exercise all authority provided for under Chapter 7, Title 57, Mississippi Code of 1972.
(j) To attach, pursuant to the power and procedure set forth in Chapter 33, Title 11, Mississippi Code of 1972, the equipment of debtors of the authority.
(k) To enter into agreements with local governments pursuant to Section 17-13-1 et seq.
(l) To render emergency assistance to other airports within the United States at an aggregate cost of less than Twenty Thousand Dollars ($20,000.00) per emergency. The assistance authorized in this paragraph must be rendered within ninety (90) days after a state of emergency has been declared by the federal government, or by the local or state government that has jurisdiction over the area where the airport needing assistance is located.
(m) To enter into joint use or similar agreements with any department or agency of the United States of America or the State of Mississippi, including any military department of the United States of America or the State of Mississippi, with respect to the use and operation of, or services provided at, any airport or other property of the authority on the terms and conditions as the authority may deem appropriate, including provisions limiting the liability of the United States of America or the State of Mississippi for loss or damage to the authority if the authority determines that the limitation of liability is reasonable, necessary and appropriate under the circumstances.
(n) To enter into mutual aid agreements with counties and municipalities for reciprocal emergency aid and assistance in case of emergencies too extensive to be dealt with unassisted; to participate in the Statewide Mutual Aid Compact (SMAC) in accordance with Section 33-15-19.
SECTION 4. Section 31-7-13, Mississippi Code of 1972, is amended as follows:
31-7-13. All agencies and governing authorities shall purchase their commodities and printing; contract for garbage collection or disposal; contract for solid waste collection or disposal; contract for sewage collection or disposal; contract for public construction; and contract for rentals as herein provided.
(a) Bidding procedure for purchases not over $5,000.00. Purchases which do not involve an expenditure of more than Five Thousand Dollars ($5,000.00), exclusive of freight or shipping charges, may be made without advertising or otherwise requesting competitive bids. However, nothing contained in this paragraph (a) shall be construed to prohibit any agency or governing authority from establishing procedures which require competitive bids on purchases of Five Thousand Dollars ($5,000.00) or less.
(b) Bidding procedure for purchases over $5,000.00 but not over $50,000.00. Purchases which involve an expenditure of more than Five Thousand Dollars ($5,000.00) but not more than Fifty Thousand Dollars ($50,000.00), exclusive of freight and shipping charges, may be made from the lowest and best bidder without publishing or posting advertisement for bids, provided at least two (2) competitive written bids have been obtained. Any state agency or community/junior college purchasing commodities or procuring construction pursuant to this paragraph (b) may authorize its purchasing agent, or his designee, to accept the lowest competitive written bid under Fifty Thousand Dollars ($50,000.00). Any governing authority purchasing commodities pursuant to this paragraph (b) may authorize its purchasing agent, or his designee, with regard to governing authorities other than counties, or its purchase clerk, or his designee, with regard to counties, to accept the lowest and best competitive written bid. Such authorization shall be made in writing by the governing authority and shall be maintained on file in the primary office of the agency and recorded in the official minutes of the governing authority, as appropriate. The purchasing agent or the purchase clerk, or their designee, as the case may be, and not the governing authority, shall be liable for any penalties and/or damages as may be imposed by law for any act or omission of the purchasing agent or purchase clerk, or their designee, constituting a violation of law in accepting any bid without approval by the governing authority. The term "competitive written bid" shall mean a bid submitted on a bid form furnished by the buying agency or governing authority and signed by authorized personnel representing the vendor, or a bid submitted on a vendor's letterhead or identifiable bid form and signed by authorized personnel representing the vendor. "Competitive" shall mean that the bids are developed based upon comparable identification of the needs and are developed independently and without knowledge of other bids or prospective bids. Any bid item for construction in excess of Five Thousand Dollars ($5,000.00) shall be broken down by components to provide detail of component description and pricing. These details shall be submitted with the written bids and become part of the bid evaluation criteria. Bids may be submitted by facsimile, electronic mail or other generally accepted method of information distribution. Bids submitted by electronic transmission shall not require the signature of the vendor's representative unless required by agencies or governing authorities.
(c) Bidding procedure for purchases over $50,000.00.
(i) Publication requirement.
1. Purchases which involve an expenditure of more than Fifty Thousand Dollars ($50,000.00), exclusive of freight and shipping charges, may be made from the lowest and best bidder after advertising for competitive bids once each week for two (2) consecutive weeks in a regular newspaper published in the county or municipality in which such agency or governing authority is located. However, all American Recovery and Reinvestment Act projects in excess of Twenty-five Thousand Dollars ($25,000.00) shall be bid. All references to American Recovery and Reinvestment Act projects in this section shall not apply to programs identified in Division B of the American Recovery and Reinvestment Act.
2. Reverse auctions shall be the primary method for receiving bids during the bidding process. If a purchasing entity determines that a reverse auction is not in the best interest of the state, then that determination must be approved by the Public Procurement Review Board. The purchasing entity shall submit a detailed explanation of why a reverse auction would not be in the best interest of the state and present an alternative process to be approved by the Public Procurement Review Board. If the Public Procurement Review Board authorizes the purchasing entity to solicit bids with a method other than reverse auction, then the purchasing entity may designate the other methods by which the bids will be received, including, but not limited to, bids sealed in an envelope, bids received electronically in a secure system, or bids received by any other method that promotes open competition and has been approved by the Office of Purchasing and Travel. However, reverse auction shall not be used for any public contract for design or construction of public facilities, including buildings, roads and bridges. The Public Procurement Review Board must approve any contract entered into by alternative process. The provisions of this item 2 shall not apply to the individual state institutions of higher learning.
3. The date as published for the bid opening shall not be less than seven (7) working days after the last published notice; however, if the purchase involves a construction project in which the estimated cost is in excess of Fifty Thousand Dollars ($50,000.00), such bids shall not be opened in less than fifteen (15) working days after the last notice is published and the notice for the purchase of such construction shall be published once each week for two (2) consecutive weeks. However, all American Recovery and Reinvestment Act projects in excess of Twenty-five Thousand Dollars ($25,000.00) shall be bid. For any projects in excess of Twenty-five Thousand Dollars ($25,000.00) under the American Recovery and Reinvestment Act, publication shall be made one (1) time and the bid opening for construction projects shall not be less than ten (10) working days after the date of the published notice. The notice of intention to let contracts or purchase equipment shall state the time and place at which bids shall be received, list the contracts to be made or types of equipment or supplies to be purchased, and, if all plans and/or specifications are not published, refer to the plans and/or specifications on file. If there is no newspaper published in the county or municipality, then such notice shall be given by posting same at the courthouse, or for municipalities at the city hall, and at two (2) other public places in the county or municipality, and also by publication once each week for two (2) consecutive weeks in some newspaper having a general circulation in the county or municipality in the above-provided manner. On the same date that the notice is submitted to the newspaper for publication, the agency or governing authority involved shall mail written notice to, or provide electronic notification to the main office of the Mississippi Procurement Technical Assistance Program under the Mississippi Development Authority that contains the same information as that in the published notice. Submissions received by the Mississippi Procurement Technical Assistance Program for projects funded by the American Recovery and Reinvestment Act shall be displayed on a separate and unique internet web page accessible to the public and maintained by the Mississippi Development Authority for the Mississippi Procurement Technical Assistance Program. Those American Recovery and Reinvestment Act related submissions shall be publicly posted within twenty-four (24) hours of receipt by the Mississippi Development Authority and the bid opening shall not occur until the submission has been posted for ten (10) consecutive days. The Department of Finance and Administration shall maintain information regarding contracts and other expenditures from the American Recovery and Reinvestment Act, on a unique internet web page accessible to the public. The Department of Finance and Administration shall promulgate rules regarding format, content and deadlines, unless otherwise specified by law, of the posting of award notices, contract execution and subsequent amendments, links to the contract documents, expenditures against the awarded contracts and general expenditures of funds from the American Recovery and Reinvestment Act. Within one (1) working day of the contract award, the agency or governing authority shall post to the designated web page maintained by the Department of Finance and Administration, notice of the award, including the award recipient, the contract amount, and a brief summary of the contract in accordance with rules promulgated by the department. Within one (1) working day of the contract execution, the agency or governing authority shall post to the designated web page maintained by the Department of Finance and Administration a summary of the executed contract and make a copy of the appropriately redacted contract documents available for linking to the designated web page in accordance with the rules promulgated by the department. The information provided by the agency or governing authority shall be posted to the web page for the duration of the American Recovery and Reinvestment Act funding or until the project is completed, whichever is longer.
(ii) Bidding process amendment procedure. If all plans and/or specifications are published in the notification, then the plans and/or specifications may not be amended. If all plans and/or specifications are not published in the notification, then amendments to the plans/specifications, bid opening date, bid opening time and place may be made, provided that the agency or governing authority maintains a list of all prospective bidders who are known to have received a copy of the bid documents and all such prospective bidders are sent copies of all amendments. This notification of amendments may be made via mail, facsimile, electronic mail or other generally accepted method of information distribution. No addendum to bid specifications may be issued within two (2) working days of the time established for the receipt of bids unless such addendum also amends the bid opening to a date not less than five (5) working days after the date of the addendum.
(iii) Filing requirement. In all cases involving governing authorities, before the notice shall be published or posted, the plans or specifications for the construction or equipment being sought shall be filed with the clerk of the board of the governing authority. In addition to these requirements, a bid file shall be established which shall indicate those vendors to whom such solicitations and specifications were issued, and such file shall also contain such information as is pertinent to the bid.
(iv) Specification restrictions.
1. Specifications pertinent to such bidding shall be written so as not to exclude comparable equipment of domestic manufacture. However, if valid justification is presented, the Department of Finance and Administration or the board of a governing authority may approve a request for specific equipment necessary to perform a specific job. Further, such justification, when placed on the minutes of the board of a governing authority, may serve as authority for that governing authority to write specifications to require a specific item of equipment needed to perform a specific job. In addition to these requirements, from and after July 1, 1990, vendors of relocatable classrooms and the specifications for the purchase of such relocatable classrooms published by local school boards shall meet all pertinent regulations of the State Board of Education, including prior approval of such bid by the State Department of Education.
2. Specifications for construction projects may include an allowance for commodities, equipment, furniture, construction materials or systems in which prospective bidders are instructed to include in their bids specified amounts for such items so long as the allowance items are acquired by the vendor in a commercially reasonable manner and approved by the agency/governing authority. Such acquisitions shall not be made to circumvent the public purchasing laws.
(v) Electronic bids. Agencies and governing authorities shall provide a secure electronic interactive system for the submittal of bids requiring competitive bidding that shall be an additional bidding option for those bidders who choose to submit their bids electronically. The Department of Finance and Administration shall provide, by regulation, the standards that agencies must follow when receiving electronic bids. Agencies and governing authorities shall make the appropriate provisions necessary to accept electronic bids from those bidders who choose to submit their bids electronically for all purchases requiring competitive bidding under this section. Any special condition or requirement for the electronic bid submission shall be specified in the advertisement for bids required by this section. Agencies or governing authorities that are currently without available high speed internet access shall be exempt from the requirement of this subparagraph (v) until such time that high speed internet access becomes available. Any county having a population of less than twenty thousand (20,000) shall be exempt from the provisions of this subparagraph (v). Any municipality having a population of less than ten thousand (10,000) shall be exempt from the provisions of this subparagraph (v). The provisions of this subparagraph (v) shall not require any bidder to submit bids electronically. When construction bids are submitted electronically, the requirement for including a certificate of responsibility, or a statement that the bid enclosed does not exceed Fifty Thousand Dollars ($50,000.00), on the exterior of the bid envelope as indicated in Section 31-3-21(1) and (2) shall be deemed in compliance with by including same as an attachment with the electronic bid submittal.
(d) Lowest and best bid decision procedure.
(i) Decision procedure. Purchases may be made from the lowest and best bidder. In determining the lowest and best bid, freight and shipping charges shall be included. Life-cycle costing, total cost bids, warranties, guaranteed buy-back provisions and other relevant provisions may be included in the best bid calculation. All best bid procedures for state agencies must be in compliance with regulations established by the Department of Finance and Administration. If any governing authority accepts a bid other than the lowest bid actually submitted, it shall place on its minutes detailed calculations and narrative summary showing that the accepted bid was determined to be the lowest and best bid, including the dollar amount of the accepted bid and the dollar amount of the lowest bid. No agency or governing authority shall accept a bid based on items not included in the specifications.
(ii) Decision procedure for Certified Purchasing Offices. In addition to the decision procedure set forth in subparagraph (i) of this paragraph (d), Certified Purchasing Offices may also use the following procedure: Purchases may be made from the bidder offering the best value. In determining the best value bid, freight and shipping charges shall be included. Life-cycle costing, total cost bids, warranties, guaranteed buy-back provisions, documented previous experience, training costs and other relevant provisions, including, but not limited to, a bidder having a local office and inventory located within the jurisdiction of the governing authority, may be included in the best value calculation. This provision shall authorize Certified Purchasing Offices to utilize a Request For Proposals (RFP) process when purchasing commodities. All best value procedures for state agencies must be in compliance with regulations established by the Department of Finance and Administration. No agency or governing authority shall accept a bid based on items or criteria not included in the specifications.
(iii) Decision procedure for Mississippi Landmarks. In addition to the decision procedure set forth in subparagraph (i) of this paragraph (d), where purchase involves renovation, restoration, or both, of the State Capitol Building or any other historical building designated for at least five (5) years as a Mississippi Landmark by the Board of Trustees of the Department of Archives and History under the authority of Sections 39-7-7 and 39-7-11, the agency or governing authority may use the following procedure: Purchases may be made from the lowest and best prequalified bidder. Prequalification of bidders shall be determined not less than fifteen (15) working days before the first published notice of bid opening. Prequalification criteria shall be limited to bidder's knowledge and experience in historical restoration, preservation and renovation. In determining the lowest and best bid, freight and shipping charges shall be included. Life-cycle costing, total cost bids, warranties, guaranteed buy-back provisions and other relevant provisions may be included in the best bid calculation. All best bid and prequalification procedures for state agencies must be in compliance with regulations established by the Department of Finance and Administration. If any governing authority accepts a bid other than the lowest bid actually submitted, it shall place on its minutes detailed calculations and narrative summary showing that the accepted bid was determined to be the lowest and best bid, including the dollar amount of the accepted bid and the dollar amount of the lowest bid. No agency or governing authority shall accept a bid based on items not included in the specifications.
(iv) Construction project negotiations authority. If the lowest and best bid is not more than ten percent (10%) above the amount of funds allocated for a public construction or renovation project, then the agency or governing authority shall be permitted to negotiate with the lowest bidder in order to enter into a contract for an amount not to exceed the funds allocated.
(e) Lease-purchase authorization. For the purposes of this section, the term "equipment" shall mean equipment, furniture and, if applicable, associated software and other applicable direct costs associated with the acquisition. Any lease-purchase of equipment which an agency is not required to lease-purchase under the master lease-purchase program pursuant to Section 31-7-10 and any lease-purchase of equipment which a governing authority elects to lease-purchase may be acquired by a lease-purchase agreement under this paragraph (e). Lease-purchase financing may also be obtained from the vendor or from a third-party source after having solicited and obtained at least two (2) written competitive bids, as defined in paragraph (b) of this section, for such financing without advertising for such bids. Solicitation for the bids for financing may occur before or after acceptance of bids for the purchase of such equipment or, where no such bids for purchase are required, at any time before the purchase thereof. No such lease-purchase agreement shall be for an annual rate of interest which is greater than the overall maximum interest rate to maturity on general obligation indebtedness permitted under Section 75-17-101, and the term of such lease-purchase agreement shall not exceed the useful life of equipment covered thereby as determined according to the upper limit of the asset depreciation range (ADR) guidelines for the Class Life Asset Depreciation Range System established by the Internal Revenue Service pursuant to the United States Internal Revenue Code and regulations thereunder as in effect on December 31, 1980, or comparable depreciation guidelines with respect to any equipment not covered by ADR guidelines. Any lease-purchase agreement entered into pursuant to this paragraph (e) may contain any of the terms and conditions which a master lease-purchase agreement may contain under the provisions of Section 31-7-10(5), and shall contain an annual allocation dependency clause substantially similar to that set forth in Section 31-7-10(8). Each agency or governing authority entering into a lease-purchase transaction pursuant to this paragraph (e) shall maintain with respect to each such lease-purchase transaction the same information as required to be maintained by the Department of Finance and Administration pursuant to Section 31-7-10(13). However, nothing contained in this section shall be construed to permit agencies to acquire items of equipment with a total acquisition cost in the aggregate of less than Ten Thousand Dollars ($10,000.00) by a single lease-purchase transaction. All equipment, and the purchase thereof by any lessor, acquired by lease-purchase under this paragraph and all lease-purchase payments with respect thereto shall be exempt from all Mississippi sales, use and ad valorem taxes. Interest paid on any lease-purchase agreement under this section shall be exempt from State of Mississippi income taxation.
(f) Alternate bid authorization. When necessary to ensure ready availability of commodities for public works and the timely completion of public projects, no more than two (2) alternate bids may be accepted by a governing authority for commodities. No purchases may be made through use of such alternate bids procedure unless the lowest and best bidder cannot deliver the commodities contained in his bid. In that event, purchases of such commodities may be made from one (1) of the bidders whose bid was accepted as an alternate.
(g) Construction contract change authorization. In the event a determination is made by an agency or governing authority after a construction contract is let that changes or modifications to the original contract are necessary or would better serve the purpose of the agency or the governing authority, such agency or governing authority may, in its discretion, order such changes pertaining to the construction that are necessary under the circumstances without the necessity of further public bids; provided that such change shall be made in a commercially reasonable manner and shall not be made to circumvent the public purchasing statutes. In addition to any other authorized person, the architect or engineer hired by an agency or governing authority with respect to any public construction contract shall have the authority, when granted by an agency or governing authority, to authorize changes or modifications to the original contract without the necessity of prior approval of the agency or governing authority when any such change or modification is less than one percent (1%) of the total contract amount. The agency or governing authority may limit the number, manner or frequency of such emergency changes or modifications.
(h) Petroleum purchase alternative. In addition to other methods of purchasing authorized in this chapter, when any agency or governing authority shall have a need for gas, diesel fuel, oils and/or other petroleum products in excess of the amount set forth in paragraph (a) of this section, such agency or governing authority may purchase the commodity after having solicited and obtained at least two (2) competitive written bids, as defined in paragraph (b) of this section. If two (2) competitive written bids are not obtained, the entity shall comply with the procedures set forth in paragraph (c) of this section. In the event any agency or governing authority shall have advertised for bids for the purchase of gas, diesel fuel, oils and other petroleum products and coal and no acceptable bids can be obtained, such agency or governing authority is authorized and directed to enter into any negotiations necessary to secure the lowest and best contract available for the purchase of such commodities.
(i) Road construction petroleum products price adjustment clause authorization. Any agency or governing authority authorized to enter into contracts for the construction, maintenance, surfacing or repair of highways, roads or streets, may include in its bid proposal and contract documents a price adjustment clause with relation to the cost to the contractor, including taxes, based upon an industry-wide cost index, of petroleum products including asphalt used in the performance or execution of the contract or in the production or manufacture of materials for use in such performance. Such industry-wide index shall be established and published monthly by the Mississippi Department of Transportation with a copy thereof to be mailed, upon request, to the clerks of the governing authority of each municipality and the clerks of each board of supervisors throughout the state. The price adjustment clause shall be based on the cost of such petroleum products only and shall not include any additional profit or overhead as part of the adjustment. The bid proposals or document contract shall contain the basis and methods of adjusting unit prices for the change in the cost of such petroleum products.
(j) State agency emergency purchase procedure. If the governing board or the executive head, or his designees, of any agency of the state shall determine that an emergency exists in regard to the purchase of any commodities or repair contracts, so that the delay incident to giving opportunity for competitive bidding would be detrimental to the interests of the state, then the head of such agency, or his designees, shall file with the Department of Finance and Administration (i) a statement explaining the conditions and circumstances of the emergency, which shall include a detailed description of the events leading up to the situation and the negative impact to the entity if the purchase is made following the statutory requirements set forth in paragraph (a), (b) or (c) of this section, and (ii) a certified copy of the appropriate minutes of the board of such agency requesting the emergency purchase, if applicable. Upon receipt of the statement and applicable board certification, the State Fiscal Officer, or his designees, may, in writing, authorize the purchase or repair without having to comply with competitive bidding requirements.
If the governing board or the executive head, or his designees, of any agency determines that an emergency exists in regard to the purchase of any commodities or repair contracts, so that the delay incident to giving opportunity for competitive bidding would threaten the health or safety of any person, or the preservation or protection of property, then the provisions in this section for competitive bidding shall not apply, and any officer or agent of the agency having general or specific authority for making the purchase or repair contract shall approve the bill presented for payment, and he shall certify in writing from whom the purchase was made, or with whom the repair contract was made.
Total purchases made under this paragraph (j) shall only be for the purpose of meeting needs created by the emergency situation. Following the emergency purchase, documentation of the purchase, including a description of the commodity purchased, the purchase price thereof and the nature of the emergency shall be filed with the Department of Finance and Administration. Any contract awarded pursuant to this paragraph (j) shall not exceed a term of one (1) year.
Purchases under the grant program established under Section 37-68-7 in response to COVID-19 and the directive that school districts create a distance learning plan and fulfill technology needs expeditiously shall be deemed an emergency purchase for purposes of this paragraph (j).
(k) Governing authority emergency purchase procedure. If the governing authority, or the governing authority acting through its designee, shall determine that an emergency exists in regard to the purchase of any commodities or repair contracts, so that the delay incident to giving opportunity for competitive bidding would be detrimental to the interest of the governing authority, then the provisions herein for competitive bidding shall not apply and any officer or agent of such governing authority having general or special authority therefor in making such purchase or repair shall approve the bill presented therefor, and he shall certify in writing thereon from whom such purchase was made, or with whom such a repair contract was made. At the board meeting next following the emergency purchase or repair contract, documentation of the purchase or repair contract, including a description of the commodity purchased, the price thereof and the nature of the emergency shall be presented to the board and shall be placed on the minutes of the board of such governing authority. Purchases under the grant program established under Section 37-68-7 in response to COVID-19 and the directive that school districts create a distance learning plan and fulfill technology needs expeditiously shall be deemed an emergency purchase for purposes of this paragraph (k).
(l) Hospital purchase, lease-purchase and lease authorization.
(i) The commissioners or board of trustees of any public hospital may contract with such lowest and best bidder for the purchase or lease-purchase of any commodity under a contract of purchase or lease-purchase agreement whose obligatory payment terms do not exceed five (5) years.
(ii) In addition to the authority granted in subparagraph (i) of this paragraph (l), the commissioners or board of trustees is authorized to enter into contracts for the lease of equipment or services, or both, which it considers necessary for the proper care of patients if, in its opinion, it is not financially feasible to purchase the necessary equipment or services. Any such contract for the lease of equipment or services executed by the commissioners or board shall not exceed a maximum of five (5) years' duration and shall include a cancellation clause based on unavailability of funds. If such cancellation clause is exercised, there shall be no further liability on the part of the lessee. Any such contract for the lease of equipment or services executed on behalf of the commissioners or board that complies with the provisions of this subparagraph (ii) shall be excepted from the bid requirements set forth in this section.
(m) Exceptions from bidding requirements. Excepted from bid requirements are:
(i) Purchasing agreements approved by department. Purchasing agreements, contracts and maximum price regulations executed or approved by the Department of Finance and Administration.
(ii) Outside equipment repairs. Repairs to equipment, when such repairs are made by repair facilities in the private sector; however, engines, transmissions, rear axles and/or other such components shall not be included in this exemption when replaced as a complete unit instead of being repaired and the need for such total component replacement is known before disassembly of the component; however, invoices identifying the equipment, specific repairs made, parts identified by number and name, supplies used in such repairs, and the number of hours of labor and costs therefor shall be required for the payment for such repairs.
(iii) In-house equipment repairs. Purchases of parts for repairs to equipment, when such repairs are made by personnel of the agency or governing authority; however, entire assemblies, such as engines or transmissions, shall not be included in this exemption when the entire assembly is being replaced instead of being repaired.
(iv) Raw gravel or dirt. Raw unprocessed deposits of gravel or fill dirt which are to be removed and transported by the purchaser.
(v) Governmental equipment auctions. Motor vehicles or other equipment purchased from a federal agency or authority, another governing authority or state agency of the State of Mississippi, or any governing authority or state agency of another state at a public auction held for the purpose of disposing of such vehicles or other equipment. Any purchase by a governing authority under the exemption authorized by this subparagraph (v) shall require advance authorization spread upon the minutes of the governing authority to include the listing of the item or items authorized to be purchased and the maximum bid authorized to be paid for each item or items.
(vi) Intergovernmental sales and transfers. Purchases, sales, transfers or trades by governing authorities or state agencies when such purchases, sales, transfers or trades are made by a private treaty agreement or through means of negotiation, from any federal agency or authority, another governing authority or state agency of the State of Mississippi, or any state agency or governing authority of another state. Nothing in this section shall permit such purchases through public auction except as provided for in subparagraph (v) of this paragraph (m). It is the intent of this section to allow governmental entities to dispose of and/or purchase commodities from other governmental entities at a price that is agreed to by both parties. This shall allow for purchases and/or sales at prices which may be determined to be below the market value if the selling entity determines that the sale at below market value is in the best interest of the taxpayers of the state. Governing authorities shall place the terms of the agreement and any justification on the minutes, and state agencies shall obtain approval from the Department of Finance and Administration, prior to releasing or taking possession of the commodities.
(vii) Perishable supplies or food. Perishable supplies or food purchased for use in connection with hospitals, the school lunch programs, homemaking programs and for the feeding of county or municipal prisoners.
(viii) Single source items. Noncompetitive items available from one (1) source only. In connection with the purchase of noncompetitive items only available from one (1) source, a certification of the conditions and circumstances requiring the purchase shall be filed by the agency with the Department of Finance and Administration and by the governing authority with the board of the governing authority. Upon receipt of that certification the Department of Finance and Administration or the board of the governing authority, as the case may be, may, in writing, authorize the purchase, which authority shall be noted on the minutes of the body at the next regular meeting thereafter. In those situations, a governing authority is not required to obtain the approval of the Department of Finance and Administration. Following the purchase, the executive head of the state agency, or his designees, shall file with the Department of Finance and Administration, documentation of the purchase, including a description of the commodity purchased, the purchase price thereof and the source from whom it was purchased.
(ix) Waste disposal facility construction contracts. Construction of incinerators and other facilities for disposal of solid wastes in which products either generated therein, such as steam, or recovered therefrom, such as materials for recycling, are to be sold or otherwise disposed of; however, in constructing such facilities, a governing authority or agency shall publicly issue requests for proposals, advertised for in the same manner as provided herein for seeking bids for public construction projects, concerning the design, construction, ownership, operation and/or maintenance of such facilities, wherein such requests for proposals when issued shall contain terms and conditions relating to price, financial responsibility, technology, environmental compatibility, legal responsibilities and such other matters as are determined by the governing authority or agency to be appropriate for inclusion; and after responses to the request for proposals have been duly received, the governing authority or agency may select the most qualified proposal or proposals on the basis of price, technology and other relevant factors and from such proposals, but not limited to the terms thereof, negotiate and enter contracts with one or more of the persons or firms submitting proposals.
(x) Hospital group purchase contracts. Supplies, commodities and equipment purchased by hospitals through group purchase programs pursuant to Section 31-7-38.
(xi) Information technology products. Purchases of information technology products made by governing authorities under the provisions of purchase schedules, or contracts executed or approved by the Mississippi Department of Information Technology Services and designated for use by governing authorities.
(xii) Energy efficiency services and equipment. Energy efficiency services and equipment acquired by school districts, community and junior colleges, institutions of higher learning and state agencies or other applicable governmental entities on a shared-savings, lease or lease-purchase basis pursuant to Section 31-7-14.
(xiii) Municipal electrical utility system fuel. Purchases of coal and/or natural gas by municipally owned electric power generating systems that have the capacity to use both coal and natural gas for the generation of electric power.
(xiv) Library books and other reference materials. Purchases by libraries or for libraries of books and periodicals; processed film, videocassette tapes, filmstrips and slides; recorded audiotapes, cassettes and diskettes; and any such items as would be used for teaching, research or other information distribution; however, equipment such as projectors, recorders, audio or video equipment, and monitor televisions are not exempt under this subparagraph.
(xv) Unmarked vehicles. Purchases of unmarked vehicles when such purchases are made in accordance with purchasing regulations adopted by the Department of Finance and Administration pursuant to Section 31-7-9(2).
(xvi) Election ballots. Purchases of ballots printed pursuant to Section 23-15-351.
(xvii) Multichannel interactive video systems. From and after July 1, 1990, contracts by Mississippi Authority for Educational Television with any private educational institution or private nonprofit organization whose purposes are educational in regard to the construction, purchase, lease or lease-purchase of facilities and equipment and the employment of personnel for providing multichannel interactive video systems (ITSF) in the school districts of this state.
(xviii) Purchases of prison industry products by the Department of Corrections, regional correctional facilities or privately owned prisons. Purchases made by the Mississippi Department of Corrections, regional correctional facilities or privately owned prisons involving any item that is manufactured, processed, grown or produced from the state's prison industries.
(xix) Undercover operations equipment. Purchases of surveillance equipment or any other high-tech equipment to be used by law enforcement agents in undercover operations, provided that any such purchase shall be in compliance with regulations established by the Department of Finance and Administration.
(xx) Junior college books for rent. Purchases by community or junior colleges of textbooks which are obtained for the purpose of renting such books to students as part of a book service system.
(xxi) Certain school district purchases. Purchases of commodities made by school districts from vendors with which any levying authority of the school district, as defined in Section 37-57-1, has contracted through competitive bidding procedures for purchases of the same commodities.
(xxii) Garbage, solid waste and sewage contracts. Contracts for garbage collection or disposal, contracts for solid waste collection or disposal and contracts for sewage collection or disposal.
(xxiii) Municipal water tank maintenance contracts. Professional maintenance program contracts for the repair or maintenance of municipal water tanks, which provide professional services needed to maintain municipal water storage tanks for a fixed annual fee for a duration of two (2) or more years.
(xxiv) Purchases of Mississippi Industries for the Blind products. Purchases made by state agencies or governing authorities involving any item that is manufactured, processed or produced by the Mississippi Industries for the Blind.
(xxv) Purchases of state-adopted textbooks. Purchases of state-adopted textbooks by public school districts.
(xxvi) Certain purchases under the Mississippi Major Economic Impact Act. Contracts entered into pursuant to the provisions of Section 57-75-9(2), (3) and (4).
(xxvii) Used heavy or specialized machinery or equipment for installation of soil and water conservation practices purchased at auction. Used heavy or specialized machinery or equipment used for the installation and implementation of soil and water conservation practices or measures purchased subject to the restrictions provided in Sections 69-27-331 through 69-27-341. Any purchase by the State Soil and Water Conservation Commission under the exemption authorized by this subparagraph shall require advance authorization spread upon the minutes of the commission to include the listing of the item or items authorized to be purchased and the maximum bid authorized to be paid for each item or items.
(xxviii) Hospital lease of equipment or services. Leases by hospitals of equipment or services if the leases are in compliance with paragraph (l)(ii).
(xxix) Purchases made pursuant to qualified cooperative purchasing agreements. Purchases made by certified purchasing offices of state agencies or governing authorities under cooperative purchasing agreements previously approved by the Office of Purchasing and Travel and established by or for any municipality, county, parish or state government or the federal government, provided that the notification to potential contractors includes a clause that sets forth the availability of the cooperative purchasing agreement to other governmental entities. Such purchases shall only be made if the use of the cooperative purchasing agreements is determined to be in the best interest of the governmental entity.
(xxx) School yearbooks. Purchases of school yearbooks by state agencies or governing authorities; provided, however, that state agencies and governing authorities shall use for these purchases the RFP process as set forth in the Mississippi Procurement Manual adopted by the Office of Purchasing and Travel.
(xxxi) Design-build
method and * * *
design-build method of contracting. Contracts entered into under the
provisions of Section 31-7-13.1, 37-101-44 or 65-1-85.
(xxxii) Toll roads and bridge construction projects. Contracts entered into under the provisions of Section 65-43-1 or 65-43-3.
(xxxiii) Certain purchases under Section 57-1-221. Contracts entered into pursuant to the provisions of Section 57-1-221.
(xxxiv) Certain transfers made pursuant to the provisions of Section 57-105-1(7). Transfers of public property or facilities under Section 57-105-1(7) and construction related to such public property or facilities.
(xxxv) Certain purchases or transfers entered into with local electrical power associations. Contracts or agreements entered into under the provisions of Section 55-3-33.
(xxxvi) Certain purchases by an academic medical center or health sciences school. Purchases by an academic medical center or health sciences school, as defined in Section 37-115-50, of commodities that are used for clinical purposes and 1. intended for use in the diagnosis of disease or other conditions or in the cure, mitigation, treatment or prevention of disease, and 2. medical devices, biological, drugs and radiation-emitting devices as defined by the United States Food and Drug Administration.
(xxxvii) Certain purchases made under the Alyce G. Clarke Mississippi Lottery Law. Contracts made by the Mississippi Lottery Corporation pursuant to the Alyce G. Clarke Mississippi Lottery Law.
(n) Term contract authorization. All contracts for the purchase of:
(i) All contracts for the purchase of commodities, equipment and public construction (including, but not limited to, repair and maintenance), may be let for periods of not more than sixty (60) months in advance, subject to applicable statutory provisions prohibiting the letting of contracts during specified periods near the end of terms of office. Term contracts for a period exceeding twenty-four (24) months shall also be subject to ratification or cancellation by governing authority boards taking office subsequent to the governing authority board entering the contract.
(ii) Bid proposals and contracts may include price adjustment clauses with relation to the cost to the contractor based upon a nationally published industry-wide or nationally published and recognized cost index. The cost index used in a price adjustment clause shall be determined by the Department of Finance and Administration for the state agencies and by the governing board for governing authorities. The bid proposal and contract documents utilizing a price adjustment clause shall contain the basis and method of adjusting unit prices for the change in the cost of such commodities, equipment and public construction.
(o) Purchase law violation prohibition and vendor penalty. No contract or purchase as herein authorized shall be made for the purpose of circumventing the provisions of this section requiring competitive bids, nor shall it be lawful for any person or concern to submit individual invoices for amounts within those authorized for a contract or purchase where the actual value of the contract or commodity purchased exceeds the authorized amount and the invoices therefor are split so as to appear to be authorized as purchases for which competitive bids are not required. Submission of such invoices shall constitute a misdemeanor punishable by a fine of not less than Five Hundred Dollars ($500.00) nor more than One Thousand Dollars ($1,000.00), or by imprisonment for thirty (30) days in the county jail, or both such fine and imprisonment. In addition, the claim or claims submitted shall be forfeited.
(p) Electrical utility petroleum-based equipment purchase procedure. When in response to a proper advertisement therefor, no bid firm as to price is submitted to an electric utility for power transformers, distribution transformers, power breakers, reclosers or other articles containing a petroleum product, the electric utility may accept the lowest and best bid therefor although the price is not firm.
(q) Fuel management system bidding procedure. Any governing authority or agency of the state shall, before contracting for the services and products of a fuel management or fuel access system, enter into negotiations with not fewer than two (2) sellers of fuel management or fuel access systems for competitive written bids to provide the services and products for the systems. In the event that the governing authority or agency cannot locate two (2) sellers of such systems or cannot obtain bids from two (2) sellers of such systems, it shall show proof that it made a diligent, good-faith effort to locate and negotiate with two (2) sellers of such systems. Such proof shall include, but not be limited to, publications of a request for proposals and letters soliciting negotiations and bids. For purposes of this paragraph (q), a fuel management or fuel access system is an automated system of acquiring fuel for vehicles as well as management reports detailing fuel use by vehicles and drivers, and the term "competitive written bid" shall have the meaning as defined in paragraph (b) of this section. Governing authorities and agencies shall be exempt from this process when contracting for the services and products of fuel management or fuel access systems under the terms of a state contract established by the Office of Purchasing and Travel.
(r) Solid waste contract proposal procedure. Before entering into any contract for garbage collection or disposal, contract for solid waste collection or disposal or contract for sewage collection or disposal, which involves an expenditure of more than Fifty Thousand Dollars ($50,000.00), a governing authority or agency shall issue publicly a request for proposals concerning the specifications for such services which shall be advertised for in the same manner as provided in this section for seeking bids for purchases which involve an expenditure of more than the amount provided in paragraph (c) of this section. Any request for proposals when issued shall contain terms and conditions relating to price, financial responsibility, technology, legal responsibilities and other relevant factors as are determined by the governing authority or agency to be appropriate for inclusion; all factors determined relevant by the governing authority or agency or required by this paragraph (r) shall be duly included in the advertisement to elicit proposals. After responses to the request for proposals have been duly received, the governing authority or agency shall select the most qualified proposal or proposals on the basis of price, technology and other relevant factors and from such proposals, but not limited to the terms thereof, negotiate and enter into contracts with one or more of the persons or firms submitting proposals. If the governing authority or agency deems none of the proposals to be qualified or otherwise acceptable, the request for proposals process may be reinitiated. Notwithstanding any other provisions of this paragraph, where a county with at least thirty-five thousand (35,000) nor more than forty thousand (40,000) population, according to the 1990 federal decennial census, owns or operates a solid waste landfill, the governing authorities of any other county or municipality may contract with the governing authorities of the county owning or operating the landfill, pursuant to a resolution duly adopted and spread upon the minutes of each governing authority involved, for garbage or solid waste collection or disposal services through contract negotiations.
(s) Minority set-aside authorization. Notwithstanding any provision of this section to the contrary, any agency or governing authority, by order placed on its minutes, may, in its discretion, set aside not more than twenty percent (20%) of its anticipated annual expenditures for the purchase of commodities from minority businesses; however, all such set-aside purchases shall comply with all purchasing regulations promulgated by the Department of Finance and Administration and shall be subject to bid requirements under this section. Set-aside purchases for which competitive bids are required shall be made from the lowest and best minority business bidder. For the purposes of this paragraph, the term "minority business" means a business which is owned by a majority of persons who are United States citizens or permanent resident aliens (as defined by the Immigration and Naturalization Service) of the United States, and who are Asian, Black, Hispanic or Native American, according to the following definitions:
(i) "Asian" means persons having origins in any of the original people of the Far East, Southeast Asia, the Indian subcontinent, or the Pacific Islands.
(ii) "Black" means persons having origins in any black racial group of Africa.
(iii) "Hispanic" means persons of Spanish or Portuguese culture with origins in Mexico, South or Central America, or the Caribbean Islands, regardless of race.
(iv) "Native American" means persons having origins in any of the original people of North America, including American Indians, Eskimos and Aleuts.
(t) Construction punch list restriction. The architect, engineer or other representative designated by the agency or governing authority that is contracting for public construction or renovation may prepare and submit to the contractor only one (1) preliminary punch list of items that do not meet the contract requirements at the time of substantial completion and one (1) final list immediately before final completion and final payment.
(u) Procurement of construction services by state institutions of higher learning. Contracts for privately financed construction of auxiliary facilities on the campus of a state institution of higher learning may be awarded by the Board of Trustees of State Institutions of Higher Learning to the lowest and best bidder, where sealed bids are solicited, or to the offeror whose proposal is determined to represent the best value to the citizens of the State of Mississippi, where requests for proposals are solicited.
(v) Insurability of bidders for public construction or other public contracts. In any solicitation for bids to perform public construction or other public contracts to which this section applies, including, but not limited to, contracts for repair and maintenance, for which the contract will require insurance coverage in an amount of not less than One Million Dollars ($1,000,000.00), bidders shall be permitted to either submit proof of current insurance coverage in the specified amount or demonstrate ability to obtain the required coverage amount of insurance if the contract is awarded to the bidder. Proof of insurance coverage shall be submitted within five (5) business days from bid acceptance.
(w) Purchase authorization clarification. Nothing in this section shall be construed as authorizing any purchase not authorized by law.
SECTION 5. This act shall take effect and be in force from and after July 1, 2021.