MISSISSIPPI LEGISLATURE

2007 Regular Session

To: Transportation

By: Representative Clarke

House Bill 917

     AN ACT TO AUTHORIZE THE MISSISSIPPI TRANSPORTATION COMMISSION, COUNTY BOARDS OF SUPERVISORS AND THE GOVERNING AUTHORITIES OF MUNICIPALITIES TO CONSTRUCT, INDIVIDUALLY OR JOINTLY WITH OTHER GOVERNMENTAL ENTITIES, TOLL ROAD OR TOLL BRIDGE PROJECTS WITHIN THE STATE; TO AUTHORIZE THE MISSISSIPPI TRANSPORTATION COMMISSION, COUNTY BOARDS OF SUPERVISORS AND THE GOVERNING AUTHORITIES OF MUNICIPALITIES TO CONTRACT WITH ANY PERSON, CORPORATION OR OTHER BUSINESS LICENSED TO DO BUSINESS IN THE STATE FOR THE PURPOSE OF CONSTRUCTING TOLL ROADS OR BRIDGES; TO PRESCRIBE THE TERMS AND CONDITIONS FOR THE LETTING OF SUCH CONTRACTS AND THE RIGHTS AND DUTIES OF THE PARTIES ENTERING INTO SUCH CONTRACTS; TO AUTHORIZE COUNTIES, CITIES AND THE STATE TO ISSUE REVENUE BONDS TO FINANCE TOLL ROAD AND TOLL BRIDGE PROJECTS; TO AMEND SECTIONS 65-3-1, 65-1-85, 31-7-13 AND 11-46-9, MISSISSIPPI CODE OF 1972, IN CONFORMITY TO THE PROVISIONS OF THIS ACT; AND FOR RELATED PURPOSES.

     BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF MISSISSIPPI:

     SECTION 1.  The Mississippi Transportation Commission, county boards of supervisors and/or the governing authorities of municipalities (hereinafter referred to as governmental entities), in their discretion, may construct, operate and maintain, individually or jointly with other governmental entities, one or more new toll roads or toll bridges in the state for motor vehicle traffic, including toll booths and related facilities, at and along such locations where an alternate untolled route exists.    All such highways, pavement, bridges, drainage related structures and other infrastructure comprising the projects shall be built and maintained in accordance with not less than the minimum highway design, construction and maintenance standards established by the contracting governmental entity for such highways, infrastructure and facilities.

     SECTION 2.  (1)  In addition to and as an alternative to any other authority granted by law including, but not limited to, Section 1 of this act, any governmental entities, as defined in Section 1 of this act, in their discretion, may contract, individually or jointly with other governmental entities, with any persons, corporations, partnerships or other businesses licensed to do business in the State of Mississippi (hereinafter referred to as "companies" or "company") for the purpose of designing, financing, constructing, operating and maintaining one or more new toll roads or toll bridges in the state for motor vehicle traffic, including toll booths and related facilities, at and along such locations where an alternate untolled route exists.  Such contracts shall provide that land held by the governmental entities, whether in fee simple, as an easement or other interest, shall be leased or assigned to a company for design, construction, operation and maintenance of roadways, highways or bridges for motor vehicle traffic, toll booths and related facilities.  All such highways, pavement, bridges, drainage related structures and other infrastructure comprising the projects shall be built and maintained in accordance with not less than the minimum highway design, construction and maintenance standards established by the contracting governmental entity for such highways, infrastructure and facilities.  The contracting governmental entity shall conduct periodic inspections of any such project throughout the term of the contract to ensure compliance by the company.  Failure of a company to comply with minimum standards established for the project by the contracting governmental entity shall constitute a breach and shall subject the company to liability on its bond or security or to rescission of the contract in accordance with the terms and provisions of the contract.

     (2)  (a)  Every contract entered into by a governmental entity under this section (except for contracts entered into with another governmental entity), at a minimum, must provide for the design and construction of a new toll road or toll bridge project and may also provide for the financing, acquisition, lease, maintenance, and/or operation of a new toll road or toll bridge project.

          (b)  If a governmental entity enters into a contract with a company as authorized by Section 2 of this act, such governmental entity shall use a competitive procurement process that provides the best value for the governmental entity.  The governmental entity may accept unsolicited proposals for a proposed new toll road or solicit proposals in accordance with this section.

          (c)  A governmental entity shall publish a request for competing proposals and qualifications in a newspaper having a general circulation within such governmental entity or, if the governmental entity is the Mississippi Transportation Commission, shall publish the request in a newspaper having a general circulation at the seat of government and, if the governmental entity has a website, shall post the request on such website.  Such request shall include the criteria used to evaluate the proposals, the relative weight given to the criteria and a deadline by which proposals must be received.  At a minimum, a proposal submitted in response to such request must contain:

              (i)  Information regarding the proposed project location, scope and limits;

              (ii)  Information regarding the company’s qualifications, experience, technical competence, and capability to develop the project; and

              (iii)  A proposed financial plan for the proposed project that includes, at a minimum, the projected project costs, projected revenues and proposed sources of funds.

     A governmental entity may interview a company submitting a solicited or unsolicited proposal.  In evaluating such proposals, a governmental entity may solicit input from other sources regarding such proposals.

          (d)  The governmental entity shall rank each proposal based on the criteria described in the request for proposals and select the company whose proposal offers the best value to the governmental entity.  The governmental entity may enter into discussions with the company whose proposal offers the best value.  If at any point during the discussions it appears to the governmental entity that the highest ranking proposal will not provide the governmental entity with the overall best value, the governmental entity may enter into discussions with the company submitting the next-highest ranking proposal.

          (e)  The governmental entity may withdraw a request for competing proposals and qualifications at any time and for any reason and may reject any one or all proposals.  In either case, the governmental entity may then publish a new request for competing proposals and qualifications.  A governmental entity shall not be required to pay any company for the costs of preparing or submitting proposals.

          (f)  The governmental entity shall prescribe the general form of a contract authorized by this section and may include any matter the governmental entity considers advantageous to it.  The governmental entity and the company shall negotiate the specific terms of the contract.

          (g)  Except as provided under this subsection (2), no such contract entered into hereunder shall be subject to the provisions of Section 65-1-8, Section 31-7-13 or any other public bid or public procurement laws of this state.

     (3)  Every contract entered into by a governmental entity under this section shall require a company to enter into bond and provide such security as the governmental entity determines may be necessary or advisable to ensure timely completion and proper execution and performance of the contract.  The governmental entities are authorized to acquire such property or interests in property as may be necessary, by gift, purchase or eminent domain, for construction and maintenance of the highways or bridges built pursuant to contracts entered into under this section.  Upon expiration, termination or rescission of the contract, all interests that the company may have in the land, infrastructure, facilities or other improvements to the property subject to contract shall terminate and automatically, by operation of law, be returned or conveyed to and vest title, ownership and possession in the contracting governmental entity.  Upon termination, expiration or rescission of the contract, the collection of tolls shall cease after all associated debts have been retired or released.

     (4)  During the term of any contract entered into under this section, the company may establish, charge and collect motor vehicle operators tolls for use of the highway or bridge and its facilities.  The amount of such tolls, and any modification thereto, shall be subject to approval by the contracting governmental entity after notice and public hearing; however, all such contracts entered into with the Mississippi Transportation Commission may require a company to pay a percentage of all tolls collected to the Mississippi Department of Transportation.  All such tolls paid to the department shall be deposited into the special bond sinking fund under Section 5 of this act and may be expended only as authorized by the Legislature.

     (5)  All statutes of this state relating to traffic regulation and control shall be applicable to motor vehicles operated upon highways and bridges constructed under this section and shall be enforceable by the Mississippi Department of Public Safety, the Mississippi Highway Safety Patrol and any other law enforcement agency having jurisdiction over such highways and bridges.

     (6)  The State of Mississippi, the Mississippi Transportation Commission, the Mississippi Department of Transportation, counties, municipalities or any other agency or political subdivision, or any officer or employee thereof, shall not be liable for any tortious act or omission arising out of the construction, maintenance or operation of any highway, bridge or roadway project under the provisions of this section where the act or omission occurs during the term of any such contract entered into by the Mississippi Transportation Commission or other governmental entity and a company.

     (7)  The powers conferred by this section shall be in addition to the powers conferred by any other law, general, special or local.  This section shall be construed as an additional and alternative method of funding all or any portion of the purchasing, building, improving, owning or operating of roadways, highways or bridges under the jurisdiction of the Mississippi Transportation Commission, county boards of supervisors or municipal governing authorities, any provision of the laws of the state or any charter of any municipality to the contrary notwithstanding.

     SECTION 3.  (1)  For the purpose of providing funds to defray the expenses of projects authorized pursuant to Sections 1 and 2 of this act, the board of supervisors of a county or the governing authorities of a municipality shall have the right to borrow money for the project, and to issue revenue bonds therefor in such principal amounts as the board of supervisors or governing authorities may determine to be necessary to provide sufficient funds to defray the expenses of projects authorized pursuant to Sections 1 and 2 of this act.  The bonds shall be payable out of any revenues derived from the project, including grants or contributions from the federal government or other sources.  Such bonds may be sold at public or private sale at not less than par and shall bear interest at a rate or rates not exceeding that allowed in Section 75-17-103.  Any such bonds so issued shall not constitute a debt of the county, the municipality or any political subdivision of the county or the city within the meaning of any constitutional, statutory or charter restriction, limitation or provision.  It shall be plainly stated on the face of each bond in substance that the bond has been issued pursuant to the authority granted in this section and that the taxing power of the county or municipality issuing the bond is not pledged to the payment of the bond or the interest on it and that the bond and the interest on it are payable solely from the revenues of the project for which the bond is issued.

     (2)  All bonds issued under the authority of this section shall bear such date or dates, shall be in such form or denomination, shall bear such rate of interest, and shall mature at such times as the county or municipality shall determine, but no bonds issued under the authority of this section shall mature more than thirty (30) years from the date of the issuance thereof and none of the bonds shall be sold for less than par and accrued interest.  All bonds shall be sold in the manner now provided by law for the sale of bonds without any restrictions, limitations, requirements or conditions applicable to the borrowing of such money and the issuance of such bonds which are not herein contained.  The denomination, form, place of payment and other details of such bonds may be determined by resolution or order of the board of supervisors of a county or the governing authorities of a municipality, and shall be executed on behalf of the county or municipality as is now provided by law.

     (3)  Before issuing any bonds under the provisions of this section, the board of supervisors of the county or the governing authorities of the municipality shall, by resolution spread upon the minutes, declare its intention to issue such bonds for the purposes authorized by this section and shall state in the resolution the amount of bonds proposed to be issued and shall likewise fix in the resolution the date upon which the board of supervisors of the county or the governing authorities of the municipality proposes to direct the issuance of the bonds.  Notice of such intention shall be published once a week for at least three (3) consecutive weeks in a newspaper published or having a general circulation in the county or the municipality, with the first publication of the notice to be made not less than twenty-one (21) days prior to the date fixed in the resolution for the issuance of the bonds and the last publication to be made not more than seven (7) days prior to such date.  If, on or before the date specified in the resolution, twenty percent (20%) or fifteen hundred (1500), whichever is less, of the qualified electors of the county or municipality shall file a written protest against the issuance of the bonds, then an election upon the issuance of the bonds shall be called, and held, as provided in this section.  If no such protest shall be filed, then the board of supervisors of the county or the governing authorities of the municipality may issue such bonds without an election on the question of the issuance of the bonds at any time within a period of two (2) years after the date specified in the resolution.

     (4)  If an election is called under the provisions of this section on the question of the issuance of bonds, the election shall be held, insofar as practicable, in the same manner as other elections are held in the county or municipality.  At the election, all qualified electors of the county or municipality may vote and the ballots used in the election shall have printed thereon a brief statement of the amount and purposes of the proposed bond issue and the words "FOR THE BOND ISSUE" and the words "AGAINST THE BOND ISSUE," and the voters shall vote by placing a cross (X) or check mark (√) opposite their choice on the proposition.

     (5)  When the results of any election provided for in this section shall have been canvassed by the election commissioners of the county or municipality and certified by them to the proper authorities, it shall be the duty of the board of supervisors of the county or the governing authorities of the municipality to determine and adjudicate whether or not a majority of the qualified electors who voted in the election voted in favor of the issuance of the bonds, and unless a majority of the qualified electors who voted in the election voted in favor of the issuance of the bonds, then the bonds shall not be issued.  Should a majority of the qualified electors who vote in the election vote in favor of the bonds, the board of supervisors of the county or the governing authorities of the municipality may issue the bonds, either in whole or in part, within two (2) years from the date of such election, or within two (2) years after final favorable determination of any litigation affecting the issuance of such bonds at such time or times, and in such amount or amounts, not exceeding that specified in the notice of the election, as shall be deemed proper.

     (6)  This section, without reference to any other statute, shall be deemed to be full and complete authority for the issuance of bonds and borrowing of money as authorized in this section by counties or municipalities, and shall be construed as an additional and alternate method therefor.  The bonds authorized by this section shall not constitute an indebtedness within the meaning of any constitutional or statutory limitation or restriction.

     SECTION 4.  (1)  (a)  A special fund, to be designated as the "Toll Road Revenue Bond Fund," is created within the State Treasury.  The fund shall be maintained by the State Treasurer as a separate and special fund, separate and apart from the General Fund of the state.  Unexpended amounts remaining in the fund at the end of a fiscal year shall not lapse into the State General Fund, and any interest earned or investment earnings on amounts in the fund shall be deposited into such fund.

          (b)  Monies deposited into the fund shall be disbursed, in the discretion of the Mississippi Transportation Commission, to pay the costs incurred in defraying the expenses of projects authorized by the Mississippi Transportation Commission pursuant to Sections 1 and 2 of this act.

     (2)  Amounts deposited into such special fund shall be disbursed to pay the expenses described in subsection (1) of this section.  If any monies in the special fund are not used within six (6) years after the date the proceeds of the bonds authorized under Sections 4 through 19 of this act are deposited into such fund, then the Mississippi Transportation Commission shall provide an accounting of such unused monies to the State Bond Commission.  Promptly after the State Bond Commission has certified, by resolution duly adopted, that the projects for which the revenue bonds have been issued shall have been completed, abandoned or cannot be completed in a timely fashion, any amounts remaining in such special fund shall be applied to pay debt service on the bonds issued under Sections 4 through 19 of this act, in accordance with the proceedings authorizing the issuance of such bonds and as directed by the State Bond Commission.

     SECTION 5.  For the purpose of providing for the payment of the principal of and interest upon bonds issued under the provisions of Sections 4 through 19 of this act, there is created a special bond sinking fund in the State Treasury.  The special bond sinking fund shall consist of the monies required to be deposited into the fund under Section 2 of this act and such other amounts as the Legislature may direct to be paid into the fund by appropriation or other authorization by the Legislature.  Unexpended amounts remaining in the special bond sinking fund at the end of a fiscal year shall not lapse into the State General Fund, and any interest earned or investment earnings on amounts in the special bond sinking fund shall be deposited into such sinking fund.

     SECTION 6.  (1)  The State Bond Commission, at one time or from time to time, may declare by resolution the necessity for issuance of revenue bonds of the State of Mississippi for the purpose of providing funds to defray the expenses of projects authorized by the Mississippi Transportation Commission pursuant to Sections 1 and 2 of this act.  Upon the adoption of a resolution by the Mississippi Transportation Commission, declaring the necessity for the issuance of the revenue bonds authorized by this section, the Mississippi Transportation Commission shall deliver a certified copy of its resolution or resolutions to the State Bond Commission.  Upon receipt of such resolution, the State Bond Commission, in its discretion, may act as the issuing agent, prescribe the form of the bonds, advertise for and accept bids, issue and sell, at public or private sale, the bonds so authorized to be sold and do any and all other things necessary and advisable in connection with the issuance and sale of such bonds.  Revenue bonds issued under this section shall be in such principal amounts as the Mississippi Transportation Commission may determine to be necessary to provide sufficient funds to defray the expenses of projects authorized by the Mississippi Transportation Commission pursuant to Sections 1 and 2 of this act.

     (2)  Any investment earnings on amounts deposited into the special fund created in Section 4 of this act shall be used to pay debt service on bonds issued under Sections 4 through 19 of this act, in accordance with the proceedings authorizing issuance of such bonds.

     SECTION 7.  The principal of and interest on the bonds authorized under Sections 4 through 19 of this act shall be payable in the manner provided in this section.  Such bonds shall bear such date or dates, be in such denomination or denominations, bear interest at such rate or rates (not to exceed the limits set forth in Section 75-17-103, Mississippi Code of 1972), be payable at such place or places within or without the State of Mississippi, shall mature absolutely at such time or times not to exceed thirty (30) years from date of issue, be redeemable before maturity at such time or times and upon such terms, with or without premium, shall bear such registration privileges, and shall be substantially in such form, all as shall be determined by resolution of the State Bond Commission.

     SECTION 8.  The bonds authorized by Sections 4 through 19 of this act shall be signed by the Chairman of the State Bond Commission, or by his facsimile signature, and the official seal of the State Bond Commission shall be affixed thereto, attested by the secretary of the commission.  The interest coupons, if any, to be attached to such bonds may be executed by the facsimile signatures of such officers.  Whenever any such bonds shall have been signed by the officials designated to sign the bonds who were in office at the time of such signing but who may have ceased to be such officers before the sale and delivery of such bonds, or who may not have been in office on the date such bonds may bear, the signatures of such officers upon such bonds and coupons shall nevertheless be valid and sufficient for all purposes and have the same effect as if the person so officially signing such bonds had remained in office until their delivery to the purchaser, or had been in office on the date such bonds may bear.  However, notwithstanding anything herein to the contrary, such bonds may be issued as provided in the Registered Bond Act of the State of Mississippi.

     SECTION 9.  All bonds and interest coupons issued under the provisions of Sections 4 through 19 of this act have all the qualities and incidents of negotiable instruments under the provisions of the Uniform Commercial Code, and in exercising the powers granted by Sections 4 through 19 of this act, the State Bond Commission shall not be required to and need not comply with the provisions of the Uniform Commercial Code.

     SECTION 10.  The State Bond Commission shall act as the issuing agent for the bonds authorized under Sections 4 through 19 of this act, prescribe the form of the bonds, advertise for and accept bids, issue and sell, at public or private sale, the bonds so authorized to be sold, pay all fees and costs incurred in such issuance and sale, and do any and all other things necessary and advisable in connection with the issuance and sale of such bonds.  The State Bond Commission is authorized and empowered to pay the costs that are incident to the sale, issuance and delivery of the bonds authorized under Sections 4 through 19 of this act from the proceeds derived from the sale of such bonds.  The State Bond Commission shall sell such bonds on sealed bids at public or private sale, and for such price as it may determine to be for the best interest of the State of Mississippi, but no such sale shall be made at a price less than par plus accrued interest to the date of delivery of the bonds to the purchaser.  All interest accruing on such bonds so issued shall be payable semiannually or annually; however, the first interest payment may be for any period of not more than one (1) year.

     Notice of the sale of any such bonds shall be published at least one time, not less than ten (10) days before the date of sale, and shall be so published in one or more newspapers published or having a general circulation in the City of Jackson, Mississippi, and in one or more other newspapers or financial journals with a national circulation, to be selected by the State Bond Commission.

     The State Bond Commission, when issuing any bonds under the authority of Sections 4 through 19 of this act, may provide that bonds, at the option of the State of Mississippi, may be called in for payment and redemption at the call price named therein and accrued interest on such date or dates named therein.

     SECTION 11.  Bonds issued under authority of Sections 4 through 19 of this act shall be revenue bonds of the state, the principal of and interest on which shall be payable solely from the revenue from projects authorized under Section 1 or 2 of this act.  The bonds shall never constitute an indebtedness of the state within the meaning of any state constitutional provision or statutory limitation, and shall never constitute or give rise to a pecuniary liability of the state, or a charge against its general credit or taxing powers, and such fact shall be plainly stated on the face of each such bond.  The bonds shall not be considered when computing any limitation of indebtedness of the state.  All bonds issued under the authority of Sections 4 through 19 of this act and all interest coupons applicable thereto shall be construed to be negotiable instruments, despite the fact that they are payable solely from a specified source.

     SECTION 12.  Upon the issuance and sale of bonds under the provisions of Sections 4 through 19 of this act, the State Bond Commission shall transfer the proceeds of any such sale or sales to a special fund created in Section 4 of this act.  The proceeds of such bonds shall be disbursed solely upon the order of the Mississippi Transportation Commission under such restrictions, if any, as may be contained in the resolution providing for the issuance of the bonds.

     SECTION 13.  The bonds authorized under Sections 4 through 19 of this act may be issued without any other proceedings or the happening of any other conditions or things other than those proceedings, conditions and things which are specified or required by Sections 4 through 19 of this act.  Any resolution providing for the issuance of bonds under the provisions of Sections 4 through 19 of this act shall become effective immediately upon its adoption by the commission, and any such resolution may be adopted at any regular or special meeting of the commission by a majority of its members.

     SECTION 14.  The bonds authorized under the authority of Sections 4 through 19 of this act may be validated in the Chancery Court of the First Judicial District of Hinds County, Mississippi, in the manner and with the force and effect provided by Chapter 13, Title 31, Mississippi Code of 1972, for the validation of county, municipal, school district and other bonds.  The notice to taxpayers required by such statutes shall be published in a newspaper published or having a general circulation in the City of Jackson, Mississippi.

     SECTION 15.  Any holder of bonds issued under the provisions of Sections 4 through 19 of this act or of any of the interest coupons pertaining thereto may, either at law or in equity, by suit, action, mandamus or other proceeding, protect and enforce any and all rights granted under Sections 4 through 19 of this act, or under such resolution, and may enforce and compel performance of all duties required by Sections 4 through 19 of this act to be performed, in order to provide for the payment of bonds and interest thereon.

     SECTION 16.  All bonds issued under the provisions of Sections 4 through 19 of this act shall be legal investments for trustees and other fiduciaries, and for savings banks, trust companies and insurance companies organized under the laws of the State of Mississippi, and such bonds shall be legal securities which may be deposited with and shall be received by all public officers and bodies of this state and all municipalities and political subdivisions for the purpose of securing the deposit of public funds.

     SECTION 17.  Bonds issued under the provisions of Sections 4 through 19 of this act and income therefrom shall be exempt from all taxation in the State of Mississippi.

     SECTION 18.  The proceeds of the bonds issued under Sections 4 through 19 of this act shall be used solely for the purposes provided in Sections 4 through 19 of this act, including the costs incident to the issuance and sale of such bonds.

     SECTION 19.  The State Treasurer is authorized, without further process of law, to certify to the Department of Finance and Administration the necessity for warrants, and the Department of Finance and Administration is authorized and directed to issue such warrants, in such amounts as may be necessary to pay when due the principal of, premium, if any, and interest on, or the accreted value of, all bonds issued under Sections 4 through 19 of this act; and the State Treasurer shall forward the necessary amount to the designated place or places of payment of such bonds in ample time to discharge such bonds, or the interest thereon, on the due dates thereof.

     SECTION 20.  Section 65-3-1, Mississippi Code of 1972, is amended as follows:

     65-3-1.  Subject only to the provisions hereinafter contained, it shall be unlawful for any person, acting privately or in any official capacity or as an employee of any subdivision of the state, to charge or collect any toll or other charge from any person for the privilege of traveling on any part of any highway which has been heretofore or may hereafter be designated as a state highway, and being a part of the state highway system, or on or across any bridge wholly within this state, which is a part of any such highway.

     For a violation of this section, any judge or chancellor may, in termtime or vacation, grant an injunction upon complaint of the Mississippi Transportation Commission.

     However, none of the provisions of this section shall prohibit the collection of any toll or other charge for the privilege of traveling on, or the use of, any causeway, bridge, tunnel, toll bridge, or any combination of such facility constructed under the provisions of Sections 65-23-101 through 65-23-119, forming a part of U.S. Highway * * * 90 across the Bay of St. Louis, or across or under the East Pascagoula River or the West Pascagoula River on * * * U.S. Highway 90.

     The provisions of this section shall be inapplicable to any toll road or bridge built or operated under the authority of Section 1 or Section 2 of House Bill No. _____, 2007 Regular Session.

     SECTION 21.  Section 65-1-85, Mississippi Code of 1972, is amended as follows:

     65-1-85.  (1)  All contracts by or on behalf of the commission for the purchase of materials, equipment and supplies shall be made in compliance with Section 31-7-1 et seq.  All contracts by or on behalf of the commission for construction, reconstruction or other public work authorized to be done under the provisions of this chapter, except maintenance, shall be made by the executive director, subject to the approval of the commission, only upon competitive bids after due advertisement as follows, to wit:

          (a) Advertisement for bids shall be in accordance with such rules and regulations, in addition to those herein provided, as may be adopted therefor by the commission, and the commission is authorized and empowered to make and promulgate such rules and regulations as it may deem proper, to provide and adopt standard specifications for road and bridge construction, and to amend such rules and regulations from time to time.

          (b)  The advertisement shall be inserted twice, being once a week for two (2) successive weeks in a newspaper published at the seat of government in Jackson, Mississippi, having a general circulation throughout the state, and no letting shall be less than fourteen (14) days nor more than sixty (60) days after the publication of the first notice of such letting, and notices of such letting may be placed in a metropolitan paper or national trade publication.

          (c)  Before advertising for such work, the executive director shall cause to be prepared and filed in thedepartment detailed plans and specifications covering the work proposed to be done and copies of the plans and specifications shall be subject to inspection by any citizen during all office hours and made available to all prospective bidders upon such reasonable terms and conditions as may be required by the commission.  A fee shall be charged equal to the cost of producing a copy of any such plans and specifications.

          (d)  All such contracts shall be let to a responsible bidder with the lowest and best bid, and a record of all bids received for construction and reconstruction shall be preserved.

          (e)  Each bid for such a construction and reconstruction contract must be accompanied by a cashier's check, a certified check or bidders bond executed by a surety company authorized to do business in the State of Mississippi, in the principal amount of not less than five percent (5%) of the bid, guaranteeing that the bidder will give bond and enter into a contract for the faithful performance of the contract according to plans and specifications on file.

          (f)  Bonds shall be required of the successful bidder in an amount equal to the contract price.  The contract price shall mean the entire cost of the particular contract let.  In the event change orders are made after the execution of a contract which results in increasing the total contract price, additional bond in the amount of the increased cost may be required.  The surety or sureties on such bonds shall be a surety company or surety companies authorized to do business in the State of Mississippi, all bonds to be payable to the State of Mississippi and to be conditioned for the prompt, faithful and efficient performance of the contract according to plans and specifications, and for the prompt payment of all persons furnishing labor, material, equipment and supplies therefor.  Such bonds shall be subject to the additional obligation that the principal and surety or sureties executing the same shall be liable to the state in a civil action instituted by the state at the instance of the commission or any officer of the state authorized in such cases, for double any amount in money or property the state may lose or be overcharged or otherwise defrauded of by reason of any wrongful or criminal act, if any, of the contractor, his agent or employees.

     (2)  With respect to equipment used in the construction, reconstruction or other public work authorized to be done under the provisions of this chapter:  the word "equipment," in addition to all equipment incorporated into or fully consumed in connection with such project, shall include the reasonable value of the use of all equipment of every kind and character and all accessories and attachments thereto which are reasonably necessary to be used and which are used in carrying out the performance of the contract, and the reasonable value of the use thereof, during the period of time the same are used in carrying out the performance of the contract, shall be the amount as agreed upon by the persons furnishing the equipment and those using the same to be paid therefor, which amount, however, shall not be in excess of the maximum current rates and charges allowable for leasing or renting as specified in Section 65-7-95; the word "labor" shall include all work performed in repairing equipment used in carrying out the performance of the contract, which repair labor is reasonably necessary to the efficient operation of said equipment; and the words "materials" and "supplies" shall include all repair parts installed in or on equipment used in carrying out the performance of the contract, which repair parts are reasonably necessary to the efficient operation of said equipment.

     (3)  The executive director, subject to the approval of the commission, shall have the right to reject any and all bids, whether such right is reserved in the notice or not.

     (4)  The commission may require the pre-qualification of any and all bidders and the failure to comply with pre-qualification requirements may be the basis for the rejection of any bid by the commission.  The commission may require the pre-qualification of any and all subcontractors before they are approved to participate in any contract awarded under this section.

     (5)  The commission may adopt rules and regulations for the termination of any previously awarded contract which is not timely proceeding toward completion.  The failure of a contractor to comply with such rules and regulations shall be a lawful basis for the commission to terminate the contract with such contractor.  In the event of a termination under such rules and regulations, the contractor shall not be entitled to any payment, benefit or damages beyond the cost of the work actually completed.

     (6)  Any contract for construction or paving of any highway may be entered into for any cost which does not exceed the amount of funds that may be made available therefor through bond issues or from other sources of revenue, and the letting of contracts for such construction or paving shall not necessarily be delayed until the funds are actually on hand, provided authorization for the issuance of necessary bonds has been granted by law to supplement other anticipated revenue, or when the department certifies to the Department of Finance and Administration and the Legislative Budget Office that projected receipts of funds by the department will be sufficient to pay such contracts as they become due and the Department of Finance and Administration determines that the projections are reasonable and receipts will be sufficient to pay the contracts as they become due.  The Department of Finance and Administration shall spread such determination on its minutes prior to the letting of any contracts based on projected receipts.  Nothing in this subsection shall prohibit the issuance of bonds, which have been authorized, at any time in the discretion of the State Bond Commission, nor to prevent investment of surplus funds in United States government bonds or State of Mississippi bonds as presently authorized by Section 12, Chapter 312, Laws of 1956.

     (7)  All other contracts for work to be done under the provisions of this chapter and for the purchase of materials, equipment and supplies to be used as provided for in this chapter shall be made in compliance with Section 31-7-1 et seq.

     (8)  The commission shall not empower or authorize the executive director, or any one or more of its members, or any engineer or other person to let or make contracts for the construction or repair of public roads, or building bridges, or for the purchase of material, equipment or supplies contrary to the provisions of this chapter as set forth in this section, except in cases of flood or other cases of emergency where the public interest requires that the work be done or the materials, equipment or supplies be purchased without the delay incident to advertising for competitive bids.  Such emergency contracts may be made without advertisement under such rules and regulations as the commission may prescribe.

     (9)  The executive director, subject to the approval of the commission, is authorized to negotiate and make agreements with communities and/or civic organizations for landscaping, beautification and maintenance of highway rights-of-way; however, nothing in this subsection shall be construed as authorization for the executive director or commission to participate in such a project to an extent greater than the average cost for maintenance of shoulders, backslopes and median areas with respect thereto.

     (10)  The executive director may negotiate and enter into contracts with private parties for the mowing of grass and trimming of vegetation on the rights-of-way of state highways whenever such practice is possible and cost effective.

     (11)  (a)  As an alternative to the method of awarding contracts as otherwise provided in this section, the commission may use the design-build method of contracting for the following:

              (i)  Projects for the Mississippi Development Authority pursuant to agreements between both governmental entities;

              (ii)  Any project with an estimated cost of not more than Ten Million Dollars ($10,000,000.00), not to exceed two (2) projects per fiscal year; and

              (iii)  Any project which has an estimated cost of more than Fifty Million Dollars ($50,000,000.00), not to exceed one (1) project per fiscal year.

          (b)  As used in this subsection, the term "design-build" method of contracting means a contract that combines the design and construction phases of a project into a single contract and the contractor is required to satisfactorily perform, at a minimum, both the design and construction of the project.

          (c)  The commission shall establish detailed criteria for the selection of the successful design-build contractor in each request for design-build proposals.  The evaluation of the selection committee is a public record and shall be maintained for a minimum of ten (10) years after project completion.

          (d)  The commission shall maintain detailed records on projects separate and apart from its regular record keeping.  The commission shall file a report to the Legislature evaluating the design-build method of contracting by comparing it to the low-bid method of contracting.  At a minimum, the report must include:

              (i)  The management goals and objectives for the design-build system of management;

              (ii)  A complete description of the components of the design-build management system, including a description of the system the department put into place on all projects managed under the system to insure that it has the complete information on highway segment costs and to insure proper analysis of any proposal the commission receives from a highway contractor;

              (iii)  The accountability systems the Transportation Department established to monitor any design-build project's compliance with specific goals and objectives for the project;

              (iv)  The outcome of any project or any interim report on an ongoing project let under a design-build management system showing compliance with the goals, objectives, policies and procedures the department set for the project; and

              (v)  The method used by the department to select projects to be let under the design-build system of management and all other systems, policies and procedures that the department considered as necessary components to a design-build management system.

          (e)  All contracts let under the provisions of this subsection shall be subject to oversight and review by the State Auditor.  The State Auditor shall file a report with the Legislature on or before January 1 of each year detailing his findings with regard to any contract let or project performed in violation of the provisions of this subsection.  The actual and necessary expenses incurred by the State Auditor in complying with this paragraph (e) shall be paid for and reimbursed by the Mississippi Department of Transportation out of funds made available for the contract or contracts let and project or projects performed.

     (12)  The provisions of this section shall not be construed to prohibit the commission from awarding or entering into contracts for the design, construction and financing of toll roads, highways and bridge projects as provided under Sections 1 and 2 of House Bill No.____, 2007 Regular Session.

     SECTION 22.  Section 31-7-13, Mississippi Code of 1972, is amended as follows:

     31-7-13.  All agencies and governing authorities shall purchase their commodities and printing; contract for garbage collection or disposal; contract for solid waste collection or disposal; contract for sewage collection or disposal; contract for public construction; and contract for rentals as herein provided.

          (a)  Bidding procedure for purchases not over $3,500.00.  Purchases which do not involve an expenditure of more than Three Thousand Five Hundred Dollars ($3,500.00), exclusive of freight or shipping charges, may be made without advertising or otherwise requesting competitive bids. However, nothing contained in this paragraph (a) shall be construed to prohibit any agency or governing authority from establishing procedures which require competitive bids on purchases of Three Thousand Five Hundred Dollars ($3,500.00) or less.

          (b)  Bidding procedure for purchases over $3,500.00 but not over $15,000.00.  Purchases which involve an expenditure of more than Three Thousand Five Hundred Dollars ($3,500.00) but not more than Fifteen Thousand Dollars ($15,000.00), exclusive of freight and shipping charges may be made from the lowest and best bidder without publishing or posting advertisement for bids, provided at least two (2) competitive written bids have been obtained.  Any governing authority purchasing commodities pursuant to this paragraph (b) may authorize its purchasing agent, or his designee, with regard to governing authorities other than counties, or its purchase clerk, or his designee, with regard to counties, to accept the lowest and best competitive written bid.  Such authorization shall be made in writing by the governing authority and shall be maintained on file in the primary office of the agency and recorded in the official minutes of the governing authority, as appropriate.  The purchasing agent or the purchase clerk, or their designee, as the case may be, and not the governing authority, shall be liable for any penalties and/or damages as may be imposed by law for any act or omission of the purchasing agent or purchase clerk, or their designee, constituting a violation of law in accepting any bid without approval by the governing authority.  The term "competitive written bid" shall mean a bid submitted on a bid form furnished by the buying agency or governing authority and signed by authorized personnel representing the vendor, or a bid submitted on a vendor's letterhead or identifiable bid form and signed by authorized personnel representing the vendor.  "Competitive" shall mean that the bids are developed based upon comparable identification of the needs and are developed independently and without knowledge of other bids or prospective bids.  Bids may be submitted by facsimile, electronic mail or other generally accepted method of information distribution.  Bids submitted by electronic transmission shall not require the signature of the vendor's representative unless required by agencies or governing authorities.

          (c)  Bidding procedure for purchases over $15,000.00.

              (i)  Publication requirement.

                   1.  Purchases which involve an expenditure of more than Fifteen Thousand Dollars ($15,000.00), exclusive of freight and shipping charges, may be made from the lowest and best bidder after advertising for competitive bids once each week for two (2) consecutive weeks in a regular newspaper published in the county or municipality in which such agency or governing authority is located.

                   2.  The purchasing entity may designate the method by which the bids will be received, including, but not limited to, bids sealed in an envelope, bids received electronically in a secure system, bids received via a reverse auction, or bids received by any other method that promotes open competition and has been approved by the Office of Purchasing and Travel.  The provisions of this part 2 of subparagraph (i) shall be repealed on July 1, 2008. 

                   3.  The date as published for the bid opening shall not be less than seven (7) working days after the last published notice; however, if the purchase involves a construction project in which the estimated cost is in excess of Fifteen Thousand Dollars ($15,000.00), such bids shall not be opened in less than fifteen (15) working days after the last notice is published and the notice for the purchase of such construction shall be published once each week for two (2) consecutive weeks.  The notice of intention to let contracts or purchase equipment shall state the time and place at which bids shall be received, list the contracts to be made or types of equipment or supplies to be purchased, and, if all plans and/or specifications are not published, refer to the plans and/or specifications on file.  If there is no newspaper published in the county or municipality, then such notice shall be given by posting same at the courthouse, or for municipalities at the city hall, and at two (2) other public places in the county or municipality, and also by publication once each week for two (2) consecutive weeks in some newspaper having a general circulation in the county or municipality in the above provided manner.  On the same date that the notice is submitted to the newspaper for publication, the agency or governing authority involved shall mail written notice to, or provide electronic notification to the main office of the Mississippi Contract Procurement Center that contains the same information as that in the published notice.

              (ii)  Bidding process amendment procedure.  If all plans and/or specifications are published in the notification, then the plans and/or specifications may not be amended.  If all plans and/or specifications are not published in the notification, then amendments to the plans/specifications, bid opening date, bid opening time and place may be made, provided that the agency or governing authority maintains a list of all prospective bidders who are known to have received a copy of the bid documents and all such prospective bidders are sent copies of all amendments.  This notification of amendments may be made via mail, facsimile, electronic mail or other generally accepted method of information distribution.  No addendum to bid specifications may be issued within two (2) working days of the time established for the receipt of bids unless such addendum also amends the bid opening to a date not less than five (5) working days after the date of the addendum.

              (iii)  Filing requirement.  In all cases involving governing authorities, before the notice shall be published or posted, the plans or specifications for the construction or equipment being sought shall be filed with the clerk of the board of the governing authority.  In addition to these requirements, a bid file shall be established which shall indicate those vendors to whom such solicitations and specifications were issued, and such file shall also contain such information as is pertinent to the bid.

              (iv)  Specification restrictions. 

                   1.  Specifications pertinent to such bidding shall be written so as not to exclude comparable equipment of domestic manufacture.  However, if valid justification is presented, the Department of Finance and Administration or the board of a governing authority may approve a request for specific equipment necessary to perform a specific job.  Further, such justification, when placed on the minutes of the board of a governing authority, may serve as authority for that governing authority to write specifications to require a specific item of equipment needed to perform a specific job.  In addition to these requirements, from and after July 1, 1990, vendors of relocatable classrooms and the specifications for the purchase of such relocatable classrooms published by local school boards shall meet all pertinent regulations of the State Board of Education, including prior approval of such bid by the State Department of Education.

                   2.  Specifications for construction projects may include an allowance for commodities, equipment, furniture, construction materials or systems in which prospective bidders are instructed to include in their bids specified amounts for such items so long as the allowance items are acquired by the vendor in a commercially reasonable manner and approved by the agency/governing authority.  Such acquisitions shall not be made to circumvent the public purchasing laws.

              (v)  Agencies and governing authorities may establish secure procedures by which bids may be submitted via electronic means.

          (d)  Lowest and best bid decision procedure.

              (i)  Decision procedure.  Purchases may be made from the lowest and best bidder.  In determining the lowest and best bid, freight and shipping charges shall be included.  Life-cycle costing, total cost bids, warranties, guaranteed buy-back provisions and other relevant provisions may be included in the best bid calculation.  All best bid procedures for state agencies must be in compliance with regulations established by the Department of Finance and Administration.  If any governing authority accepts a bid other than the lowest bid actually submitted, it shall place on its minutes detailed calculations and narrative summary showing that the accepted bid was determined to be the lowest and best bid, including the dollar amount of the accepted bid and the dollar amount of the lowest bid.  No agency or governing authority shall accept a bid based on items not included in the specifications.

              (ii)  Decision procedure for Certified Purchasing Offices.  In addition to the decision procedure set forth in paragraph (d)(i), Certified Purchasing Offices may also use the following procedure:  Purchases may be made from the bidder offering the best value.  In determining the best value bid, freight and shipping charges shall be included.  Life-cycle costing, total cost bids, warranties, guaranteed buy-back provisions, documented previous experience, training costs and other relevant provisions may be included in the best value calculation.  This provision shall authorize Certified Purchasing Offices to utilize a Request For Proposals (RFP) process when purchasing commodities.  All best value procedures for state agencies must be in compliance with regulations established by the Department of Finance and Administration.  No agency or governing authority shall accept a bid based on items or criteria not included in the specifications.

              (iii)  Construction project negotiations authority.  If the lowest and best bid is not more than ten percent (10%) above the amount of funds allocated for a public construction or renovation project, then the agency or governing authority shall be permitted to negotiate with the lowest bidder in order to enter into a contract for an amount not to exceed the funds allocated.

          (e)  Lease-purchase authorization.  For the purposes of this section, the term "equipment" shall mean equipment, furniture and, if applicable, associated software and other applicable direct costs associated with the acquisition.  Any lease-purchase of equipment which an agency is not required to lease-purchase under the master lease-purchase program pursuant to Section 31-7-10 and any lease-purchase of equipment which a governing authority elects to lease-purchase may be acquired by a lease-purchase agreement under this paragraph (e).  Lease-purchase financing may also be obtained from the vendor or from a third-party source after having solicited and obtained at least two (2) written competitive bids, as defined in paragraph (b) of this section, for such financing without advertising for such bids.  Solicitation for the bids for financing may occur before or after acceptance of bids for the purchase of such equipment or, where no such bids for purchase are required, at any time before the purchase thereof.  No such lease-purchase agreement shall be for an annual rate of interest which is greater than the overall maximum interest rate to maturity on general obligation indebtedness permitted under Section 75-17-101, and the term of such lease-purchase agreement shall not exceed the useful life of equipment covered thereby as determined according to the upper limit of the asset depreciation range (ADR) guidelines for the Class Life Asset Depreciation Range System established by the Internal Revenue Service pursuant to the United States Internal Revenue Code and regulations thereunder as in effect on December 31, 1980, or comparable depreciation guidelines with respect to any equipment not covered by ADR guidelines.  Any lease-purchase agreement entered into pursuant to this paragraph (e) may contain any of the terms and conditions which a master lease-purchase agreement may contain under the provisions of Section 31-7-10(5), and shall contain an annual allocation dependency clause substantially similar to that set forth in Section 31-7-10(8).  Each agency or governing authority entering into a lease-purchase transaction pursuant to this paragraph (e) shall maintain with respect to each such lease-purchase transaction the same information as required to be maintained by the Department of Finance and Administration pursuant to Section 31-7-10(13).  However, nothing contained in this section shall be construed to permit agencies to acquire items of equipment with a total acquisition cost in the aggregate of less than Ten Thousand Dollars ($10,000.00) by a single lease-purchase transaction.  All equipment, and the purchase thereof by any lessor, acquired by lease-purchase under this paragraph and all lease-purchase payments with respect thereto shall be exempt from all Mississippi sales, use and ad valorem taxes.  Interest paid on any lease-purchase agreement under this section shall be exempt from State of Mississippi income taxation.

          (f)  Alternate bid authorization.  When necessary to ensure ready availability of commodities for public works and the timely completion of public projects, no more than two (2) alternate bids may be accepted by a governing authority for commodities.  No purchases may be made through use of such alternate bids procedure unless the lowest and best bidder cannot deliver the commodities contained in his bid.  In that event, purchases of such commodities may be made from one (1) of the bidders whose bid was accepted as an alternate.

          (g)  Construction contract change authorization.  In the event a determination is made by an agency or governing authority after a construction contract is let that changes or modifications to the original contract are necessary or would better serve the purpose of the agency or the governing authority, such agency or governing authority may, in its discretion, order such changes pertaining to the construction that are necessary under the circumstances without the necessity of further public bids; provided that such change shall be made in a commercially reasonable manner and shall not be made to circumvent the public purchasing statutes.  In addition to any other authorized person, the architect or engineer hired by an agency or governing authority with respect to any public construction contract shall have the authority, when granted by an agency or governing authority, to authorize changes or modifications to the original contract without the necessity of prior approval of the agency or governing authority when any such change or modification is less than one percent (1%) of the total contract amount.  The agency or governing authority may limit the number, manner or frequency of such emergency changes or modifications.

          (h)  Petroleum purchase alternative.  In addition to other methods of purchasing authorized in this chapter, when any agency or governing authority shall have a need for gas, diesel fuel, oils and/or other petroleum products in excess of the amount set forth in paragraph (a) of this section, such agency or governing authority may purchase the commodity after having solicited and obtained at least two (2) competitive written bids, as defined in paragraph (b) of this section.  If two (2) competitive written bids are not obtained, the entity shall comply with the procedures set forth in paragraph (c) of this section.  In the event any agency or governing authority shall have advertised for bids for the purchase of gas, diesel fuel, oils and other petroleum products and coal and no acceptable bids can be obtained, such agency or governing authority is authorized and directed to enter into any negotiations necessary to secure the lowest and best contract available for the purchase of such commodities.

          (i)  Road construction petroleum products price adjustment clause authorization.  Any agency or governing authority authorized to enter into contracts for the construction, maintenance, surfacing or repair of highways, roads or streets, may include in its bid proposal and contract documents a price adjustment clause with relation to the cost to the contractor, including taxes, based upon an industry-wide cost index, of petroleum products including asphalt used in the performance or execution of the contract or in the production or manufacture of materials for use in such performance.  Such industry-wide index shall be established and published monthly by the Mississippi Department of Transportation with a copy thereof to be mailed, upon request, to the clerks of the governing authority of each municipality and the clerks of each board of supervisors throughout the state.  The price adjustment clause shall be based on the cost of such petroleum products only and shall not include any additional profit or overhead as part of the adjustment.  The bid proposals or document contract shall contain the basis and methods of adjusting unit prices for the change in the cost of such petroleum products.

          (j)  State agency emergency purchase procedure.  If the governing board or the executive head, or his designee, of any agency of the state shall determine that an emergency exists in regard to the purchase of any commodities or repair contracts, so that the delay incident to giving opportunity for competitive bidding would be detrimental to the interests of the state, then the provisions herein for competitive bidding shall not apply and the head of such agency shall be authorized to make the purchase or repair.  Total purchases so made shall only be for the purpose of meeting needs created by the emergency situation.  In the event such executive head is responsible to an agency board, at the meeting next following the emergency purchase, documentation of the purchase, including a description of the commodity purchased, the purchase price thereof and the nature of the emergency shall be presented to the board and placed on the minutes of the board of such agency.  The head of such agency, or his designee, shall, at the earliest possible date following such emergency purchase, file with the Department of Finance and Administration (i) a statement explaining the conditions and circumstances of the emergency, which shall include a detailed description of the events leading up to the situation and the negative impact to the entity if the purchase is made following the statutory requirements set forth in paragraph (a), (b) or (c) of this section, and (ii) a certified copy of the appropriate minutes of the board of such agency, if applicable.  On or before September 1 of each year, the State Auditor shall prepare and deliver to the Senate Fees, Salaries and Administration Committee, the House Fees and Salaries of Public Officers Committee and the Joint Legislative Budget Committee a report containing a list of all state agency emergency purchases and supporting documentation for each emergency purchase.

          (k)  Governing authority emergency purchase procedure.  If the governing authority, or the governing authority acting through its designee, shall determine that an emergency exists in regard to the purchase of any commodities or repair contracts, so that the delay incident to giving opportunity for competitive bidding would be detrimental to the interest of the governing authority, then the provisions herein for competitive bidding shall not apply and any officer or agent of such governing authority having general or special authority therefor in making such purchase or repair shall approve the bill presented therefor, and he shall certify in writing thereon from whom such purchase was made, or with whom such a repair contract was made.  At the board meeting next following the emergency purchase or repair contract, documentation of the purchase or repair contract, including a description of the commodity purchased, the price thereof and the nature of the emergency shall be presented to the board and shall be placed on the minutes of the board of such governing authority.

          (l)  Hospital purchase, lease-purchase and lease authorization.

              (i)  The commissioners or board of trustees of any public hospital may contract with such lowest and best bidder for the purchase or lease-purchase of any commodity under a contract of purchase or lease-purchase agreement whose obligatory payment terms do not exceed five (5) years.

              (ii)  In addition to the authority granted in subparagraph (i) of this paragraph (l), the commissioners or board of trustees is authorized to enter into contracts for the lease of equipment or services, or both, which it considers necessary for the proper care of patients if, in its opinion, it is not financially feasible to purchase the necessary equipment or services.  Any such contract for the lease of equipment or services executed by the commissioners or board shall not exceed a maximum of five (5) years' duration and shall include a cancellation clause based on unavailability of funds.  If such cancellation clause is exercised, there shall be no further liability on the part of the lessee.  Any such contract for the lease of equipment or services executed on behalf of the commissioners or board that complies with the provisions of this subparagraph (ii) shall be excepted from the bid requirements set forth in this section.

          (m)  Exceptions from bidding requirements.  Excepted from bid requirements are:

              (i)  Purchasing agreements approved by department.  Purchasing agreements, contracts and maximum price regulations executed or approved by the Department of Finance and Administration.

              (ii)  Outside equipment repairs.  Repairs to equipment, when such repairs are made by repair facilities in the private sector; however, engines, transmissions, rear axles and/or other such components shall not be included in this exemption when replaced as a complete unit instead of being repaired and the need for such total component replacement is known before disassembly of the component; however, invoices identifying the equipment, specific repairs made, parts identified by number and name, supplies used in such repairs, and the number of hours of labor and costs therefor shall be required for the payment for such repairs.

              (iii)  In-house equipment repairs.  Purchases of parts for repairs to equipment, when such repairs are made by personnel of the agency or governing authority; however, entire assemblies, such as engines or transmissions, shall not be included in this exemption when the entire assembly is being replaced instead of being repaired.

              (iv)  Raw gravel or dirt.  Raw unprocessed deposits of gravel or fill dirt which are to be removed and transported by the purchaser.

              (v)  Governmental equipment auctions.  Motor vehicles or other equipment purchased from a federal agency or authority, another governing authority or state agency of the State of Mississippi, or any governing authority or state agency of another state at a public auction held for the purpose of disposing of such vehicles or other equipment.  Any purchase by a governing authority under the exemption authorized by this subparagraph (v) shall require advance authorization spread upon the minutes of the governing authority to include the listing of the item or items authorized to be purchased and the maximum bid authorized to be paid for each item or items.

              (vi)  Intergovernmental sales and transfers.  Purchases, sales, transfers or trades by governing authorities or state agencies when such purchases, sales, transfers or trades are made by a private treaty agreement or through means of negotiation, from any federal agency or authority, another governing authority or state agency of the State of Mississippi, or any state agency or governing authority of another state.  Nothing in this section shall permit such purchases through public auction except as provided for in subparagraph (v) of this section.  It is the intent of this section to allow governmental entities to dispose of and/or purchase commodities from other governmental entities at a price that is agreed to by both parties.  This shall allow for purchases and/or sales at prices which may be determined to be below the market value if the selling entity determines that the sale at below market value is in the best interest of the taxpayers of the state.  Governing authorities shall place the terms of the agreement and any justification on the minutes, and state agencies shall obtain approval from the Department of Finance and Administration, prior to releasing or taking possession of the commodities.

              (vii)  Perishable supplies or food.  Perishable supplies or food purchased for use in connection with hospitals, the school lunch programs, homemaking programs and for the feeding of county or municipal prisoners.

              (viii)  Single source items.  Noncompetitive items available from one (1) source only.  In connection with the purchase of noncompetitive items only available from one (1) source, a certification of the conditions and circumstances requiring the purchase shall be filed by the agency with the Department of Finance and Administration and by the governing authority with the board of the governing authority.  Upon receipt of that certification the Department of Finance and Administration or the board of the governing authority, as the case may be, may, in writing, authorize the purchase, which authority shall be noted on the minutes of the body at the next regular meeting thereafter.  In those situations, a governing authority is not required to obtain the approval of the Department of Finance and Administration.

              (ix)  Waste disposal facility construction contracts.  Construction of incinerators and other facilities for disposal of solid wastes in which products either generated therein, such as steam, or recovered therefrom, such as materials for recycling, are to be sold or otherwise disposed of; however, in constructing such facilities, a governing authority or agency shall publicly issue requests for proposals, advertised for in the same manner as provided herein for seeking bids for public construction projects, concerning the design, construction, ownership, operation and/or maintenance of such facilities, wherein such requests for proposals when issued shall contain terms and conditions relating to price, financial responsibility, technology, environmental compatibility, legal responsibilities and such other matters as are determined by the governing authority or agency to be appropriate for inclusion; and after responses to the request for proposals have been duly received, the governing authority or agency may select the most qualified proposal or proposals on the basis of price, technology and other relevant factors and from such proposals, but not limited to the terms thereof, negotiate and enter contracts with one or more of the persons or firms submitting proposals.

              (x)  Hospital group purchase contracts.  Supplies, commodities and equipment purchased by hospitals through group purchase programs pursuant to Section 31-7-38.

              (xi)  Information technology products.  Purchases of information technology products made by governing authorities under the provisions of purchase schedules, or contracts executed or approved by the Mississippi Department of Information Technology Services and designated for use by governing authorities.

              (xii)  Energy efficiency services and equipment.  Energy efficiency services and equipment acquired by school districts, community and junior colleges, institutions of higher learning and state agencies or other applicable governmental entities on a shared-savings, lease or lease-purchase basis pursuant to Section 31-7-14.

              (xiii)  Municipal electrical utility system fuel.  Purchases of coal and/or natural gas by municipally-owned electric power generating systems that have the capacity to use both coal and natural gas for the generation of electric power.

              (xiv)  Library books and other reference materials.  Purchases by libraries or for libraries of books and periodicals; processed film, video cassette tapes, filmstrips and slides; recorded audio tapes, cassettes and diskettes; and any such items as would be used for teaching, research or other information distribution; however, equipment such as projectors, recorders, audio or video equipment, and monitor televisions are not exempt under this subparagraph.

              (xv)  Unmarked vehicles.  Purchases of unmarked vehicles when such purchases are made in accordance with purchasing regulations adopted by the Department of Finance and Administration pursuant to Section 31-7-9(2).

              (xvi)  Election ballots.  Purchases of ballots printed pursuant to Section 23-15-351.

              (xvii)  Multichannel interactive video systems.  From and after July 1, 1990, contracts by Mississippi Authority for Educational Television with any private educational institution or private nonprofit organization whose purposes are educational in regard to the construction, purchase, lease or lease-purchase of facilities and equipment and the employment of personnel for providing multichannel interactive video systems (ITSF) in the school districts of this state.

              (xviii)  Purchases of prison industry products.  From and after January 1, 1991, purchases made by state agencies  or governing authorities involving any item that is manufactured, processed, grown or produced from the state's prison industries.

              (xix)  Undercover operations equipment.  Purchases of surveillance equipment or any other high-tech equipment to be used by law enforcement agents in undercover operations, provided that any such purchase shall be in compliance with regulations established by the Department of Finance and Administration.

              (xx)  Junior college books for rent.  Purchases by community or junior colleges of textbooks which are obtained for the purpose of renting such books to students as part of a book service system.

              (xxi)  Certain school district purchases.  Purchases of commodities made by school districts from vendors with which any levying authority of the school district, as defined in Section 37-57-1, has contracted through competitive bidding procedures for purchases of the same commodities.

              (xxii)  Garbage, solid waste and sewage contracts.  Contracts for garbage collection or disposal, contracts for solid waste collection or disposal and contracts for sewage collection or disposal.

              (xxiii)  Municipal water tank maintenance contracts.  Professional maintenance program contracts for the repair or maintenance of municipal water tanks, which provide professional services needed to maintain municipal water storage tanks for a fixed annual fee for a duration of two (2) or more years.

              (xxiv)  Purchases of Mississippi Industries for the Blind products.  Purchases made by state agencies or governing authorities involving any item that is manufactured, processed or produced by the Mississippi Industries for the Blind.

              (xxv)  Purchases of state-adopted textbooks.  Purchases of state-adopted textbooks by public school districts.

              (xxvi)  Certain purchases under the Mississippi Major Economic Impact Act.  Contracts entered into pursuant to the provisions of Section 57-75-9(2) and (3).

              (xxvii)  Used heavy or specialized machinery or equipment for installation of soil and water conservation practices purchased at auction.  Used heavy or specialized machinery or equipment used for the installation and implementation of soil and water conservation practices or measures purchased subject to the restrictions provided in Sections 69-27-331 through 69-27-341.  Any purchase by the State Soil and Water Conservation Commission under the exemption authorized by this subparagraph shall require advance authorization spread upon the minutes of the commission to include the listing of the item or items authorized to be purchased and the maximum bid authorized to be paid for each item or items.

              (xxviii)  Hospital lease of equipment or services.  Leases by hospitals of equipment or services if the leases are in compliance with paragraph (l)(ii).

              (xxix)  Purchases made pursuant to qualified cooperative purchasing agreements.  Purchases made by certified purchasing offices of state agencies or governing authorities under cooperative purchasing agreements previously approved by the Office of Purchasing and Travel and established by or for any municipality, county, parish or state government or the federal government, provided that the notification to potential contractors includes a clause that sets forth the availability of the cooperative purchasing agreement to other governmental entities.  Such purchases shall only be made if the use of the cooperative purchasing agreements is determined to be in the best interest of the governmental entity.

              (xxx)  School yearbooks.  Purchases of school yearbooks by state agencies or governing authorities; provided, however, that state agencies and governing authorities shall use for these purchases the RFP process as set forth in the Mississippi Procurement Manual adopted by the Office of Purchasing and Travel.

              (xxxi)  Toll roads and bridge construction projects.  Contracts entered into under the provisions of Section 1 or 2 of House Bill No.____, 2007 Regular Session.

          (n)  Term contract authorization.  All contracts for the purchase of:

              (i)  All contracts for the purchase of commodities, equipment and public construction (including, but not limited to, repair and maintenance), may be let for periods of not more than sixty (60) months in advance, subject to applicable statutory provisions prohibiting the letting of contracts during specified periods near the end of terms of office.  Term contracts for a period exceeding twenty-four (24) months shall also be subject to ratification or cancellation by governing authority boards taking office subsequent to the governing authority board entering the contract.

              (ii)  Bid proposals and contracts may include price adjustment clauses with relation to the cost to the contractor based upon a nationally published industry-wide or nationally published and recognized cost index.  The cost index used in a price adjustment clause shall be determined by the Department of Finance and Administration for the state agencies and by the governing board for governing authorities.  The bid proposal and contract documents utilizing a price adjustment clause shall contain the basis and method of adjusting unit prices for the change in the cost of such commodities, equipment and public construction.

          (o)  Purchase law violation prohibition and vendor penalty.  No contract or purchase as herein authorized shall be made for the purpose of circumventing the provisions of this section requiring competitive bids, nor shall it be lawful for any person or concern to submit individual invoices for amounts within those authorized for a contract or purchase where the actual value of the contract or commodity purchased exceeds the authorized amount and the invoices therefor are split so as to appear to be authorized as purchases for which competitive bids are not required.  Submission of such invoices shall constitute a misdemeanor punishable by a fine of not less than Five Hundred Dollars ($500.00) nor more than One Thousand Dollars ($1,000.00), or by imprisonment for thirty (30) days in the county jail, or both such fine and imprisonment.  In addition, the claim or claims submitted shall be forfeited.

          (p)  Electrical utility petroleum-based equipment purchase procedure.  When in response to a proper advertisement therefor, no bid firm as to price is submitted to an electric utility for power transformers, distribution transformers, power breakers, reclosers or other articles containing a petroleum product, the electric utility may accept the lowest and best bid therefor although the price is not firm.

          (q)  Fuel management system bidding procedure.  Any governing authority or agency of the state shall, before contracting for the services and products of a fuel management or fuel access system, enter into negotiations with not fewer than two (2) sellers of fuel management or fuel access systems for competitive written bids to provide the services and products for the systems.  In the event that the governing authority or agency cannot locate two (2) sellers of such systems or cannot obtain bids from two (2) sellers of such systems, it shall show proof that it made a diligent, good-faith effort to locate and negotiate with two (2) sellers of such systems.  Such proof shall include, but not be limited to, publications of a request for proposals and letters soliciting negotiations and bids.  For purposes of this paragraph (q), a fuel management or fuel access system is an automated system of acquiring fuel for vehicles as well as management reports detailing fuel use by vehicles and drivers, and the term "competitive written bid" shall have the meaning as defined in paragraph (b) of this section.  Governing authorities and agencies shall be exempt from this process when contracting for the services and products of a fuel management or fuel access systems under the terms of a state contract established by the Office of Purchasing and Travel.

          (r)  Solid waste contract proposal procedure.  Before entering into any contract for garbage collection or disposal, contract for solid waste collection or disposal or contract for sewage collection or disposal, which involves an expenditure of more than Fifty Thousand Dollars ($50,000.00), a governing authority or agency shall issue publicly a request for proposals concerning the specifications for such services which shall be advertised for in the same manner as provided in this section for seeking bids for purchases which involve an expenditure of more than the amount provided in paragraph (c) of this section.  Any request for proposals when issued shall contain terms and conditions relating to price, financial responsibility, technology, legal responsibilities and other relevant factors as are determined by the governing authority or agency to be appropriate for inclusion; all factors determined relevant by the governing authority or agency or required by this paragraph (r) shall be duly included in the advertisement to elicit proposals.  After responses to the request for proposals have been duly received, the governing authority or agency shall select the most qualified proposal or proposals on the basis of price, technology and other relevant factors and from such proposals, but not limited to the terms thereof, negotiate and enter contracts with one or more of the persons or firms submitting proposals.  If the governing authority or agency deems none of the proposals to be qualified or otherwise acceptable, the request for proposals process may be reinitiated.  Notwithstanding any other provisions of this paragraph, where a county with at least thirty-five thousand (35,000) nor more than forty thousand (40,000) population, according to the 1990 federal decennial census, owns or operates a solid waste landfill, the governing authorities of any other county or municipality may contract with the governing authorities of the county owning or operating the landfill, pursuant to a resolution duly adopted and spread upon the minutes of each governing authority involved, for garbage or solid waste collection or disposal services through contract negotiations.

          (s)  Minority set-aside authorization.  Notwithstanding any provision of this section to the contrary, any agency or governing authority, by order placed on its minutes, may, in its discretion, set aside not more than twenty percent (20%) of its anticipated annual expenditures for the purchase of commodities from minority businesses; however, all such set-aside purchases shall comply with all purchasing regulations promulgated by the Department of Finance and Administration and shall be subject to bid requirements under this section.  Set-aside purchases for which competitive bids are required shall be made from the lowest and best minority business bidder.  For the purposes of this paragraph, the term "minority business" means a business which is owned by a majority of persons who are United States citizens or permanent resident aliens (as defined by the Immigration and Naturalization Service) of the United States, and who are Asian, Black, Hispanic or Native American, according to the following definitions:

              (i)  "Asian" means persons having origins in any of the original people of the Far East, Southeast Asia, the Indian subcontinent, or the Pacific Islands.

              (ii)  "Black" means persons having origins in any black racial group of Africa.

              (iii)  "Hispanic" means persons of Spanish or Portuguese culture with origins in Mexico, South or Central America, or the Caribbean Islands, regardless of race.

              (iv)  "Native American" means persons having origins in any of the original people of North America, including American Indians, Eskimos and Aleuts.

          (t)  Construction punch list restriction.  The architect, engineer or other representative designated by the agency or governing authority that is contracting for public construction or renovation may prepare and submit to the contractor only one (1) preliminary punch list of items that do not meet the contract requirements at the time of substantial completion and one (1) final list immediately before final completion and final payment.

          (u)  Purchase authorization clarification.  Nothing in this section shall be construed as authorizing any purchase not authorized by law.

     SECTION 23.  Section 11-46-9, Mississippi Code of 1972, is amended as follows:

     11-46-9.  (1)  A governmental entity and its employees acting within the course and scope of their employment or duties shall not be liable for any claim:

          (a)  Arising out of a legislative or judicial action or inaction, or administrative action or inaction of a legislative or judicial nature;

          (b)  Arising out of any act or omission of an employee of a governmental entity exercising ordinary care in reliance upon, or in the execution or performance of, or in the failure to execute or perform, a statute, ordinance or regulation, whether or not the statute, ordinance or regulation be valid;

          (c)  Arising out of any act or omission of an employee of a governmental entity engaged in the performance or execution of duties or activities relating to police or fire protection unless the employee acted in reckless disregard of the safety and well-being of any person not engaged in criminal activity at the time of injury;

          (d)  Based upon the exercise or performance or the failure to exercise or perform a discretionary function or duty on the part of a governmental entity or employee thereof, whether or not the discretion be abused;

          (e)  Arising out of an injury caused by adopting or failing to adopt a statute, ordinance or regulation;

          (f)  Which is limited or barred by the provisions of any other law;

          (g)  Arising out of the exercise of discretion in determining whether or not to seek or provide the resources necessary for the purchase of equipment, the construction or maintenance of facilities, the hiring of personnel and, in general, the provision of adequate governmental services;

          (h)  Arising out of the issuance, denial, suspension or revocation of, or the failure or refusal to issue, deny, suspend or revoke any privilege, ticket, pass, permit, license, certificate, approval, order or similar authorization where the governmental entity or its employee is authorized by law to determine whether or not such authorization should be issued, denied, suspended or revoked unless such issuance, denial, suspension or revocation, or failure or refusal thereof, is of a malicious or arbitrary and capricious nature;

          (i)  Arising out of the assessment or collection of any tax or fee;

          (j)  Arising out of the detention of any goods or merchandise by any law enforcement officer, unless such detention is of a malicious or arbitrary and capricious nature;

          (k)  Arising out of the imposition or establishment of a quarantine, whether such quarantine relates to persons or property;

          (l)  Of any claimant who is an employee of a governmental entity and whose injury is covered by the Workers' Compensation Law of this state by benefits furnished by the governmental entity by which he is employed;

          (m)  Of any claimant who at the time the claim arises is an inmate of any detention center, jail, workhouse, penal farm, penitentiary or other such institution, regardless of whether such claimant is or is not an inmate of any detention center, jail, workhouse, penal farm, penitentiary or other such institution when the claim is filed;

          (n)  Arising out of any work performed by a person convicted of a crime when the work is performed pursuant to any sentence or order of any court or pursuant to laws of the State of Mississippi authorizing or requiring such work;

          (o)  Under circumstances where liability has been or is hereafter assumed by the United States, to the extent of such assumption of liability, including, but not limited to, any claim based on activities of the Mississippi National Guard when such claim is cognizable under the National Guard Tort Claims Act of the United States, 32 USCS 715 (32 USCS 715), or when such claim accrues as a result of active federal service or state service at the call of the Governor for quelling riots and civil disturbances;

          (p)  Arising out of a plan or design for construction or improvements to public property, including, but not limited to, public buildings, highways, roads, streets, bridges, levees, dikes, dams, impoundments, drainage channels, diversion channels, harbors, ports, wharfs or docks, where such plan or design has been approved in advance of the construction or improvement by the legislative body or governing authority of a governmental entity or by some other body or administrative agency, exercising discretion by authority to give such approval, and where such plan or design is in conformity with engineering or design standards in effect at the time of preparation of the plan or design;

          (q)  Arising out of an injury caused solely by the effect of weather conditions on the use of streets and highways;

          (r)  Arising out of the lack of adequate personnel or facilities at a state hospital or state corrections facility if reasonable use of available appropriations has been made to provide such personnel or facilities;

          (s)  Arising out of loss, damage or destruction of property of a patient or inmate of a state institution;

          (t)  Arising out of any loss of benefits or compensation due under a program of public assistance or public welfare;

          (u)  Arising out of or resulting from riots, unlawful assemblies, unlawful public demonstrations, mob violence or civil disturbances;

          (v)  Arising out of an injury caused by a dangerous condition on property of the governmental entity that was not caused by the negligent or other wrongful conduct of an employee of the governmental entity or of which the governmental entity did not have notice, either actual or constructive, and adequate opportunity to protect or warn against; provided, however, that a governmental entity shall not be liable for the failure to warn of a dangerous condition which is obvious to one exercising due care;

          (w)  Arising out of the absence, condition, malfunction or removal by third parties of any sign, signal, warning device, illumination device, guardrail or median barrier, unless the absence, condition, malfunction or removal is not corrected by the governmental entity responsible for its maintenance within a reasonable time after actual or constructive notice; * * *

          (x)  Arising out of the administration of corporal punishment or the taking of any action to maintain control and discipline of students, as defined in Section 37-11-57, by a teacher, assistant teacher, principal or assistant principal of a public school district in the state unless the teacher, assistant teacher, principal or assistant principal acted in bad faith or with malicious purpose or in a manner exhibiting a wanton and willful disregard of human rights or safety; or

          (y)  Arising out of the construction, maintenance or operation of any highway, bridge or roadway project entered into by the Mississippi Transportation Commission or other governmental entity and a company under the provisions of Section 1 or 2 of House Bill No. ____, 2007 Regular Session, where the act or omission occurs during the term of any such contract.

     (2)  A governmental entity shall also not be liable for any claim where the governmental entity:

          (a)  Is inactive and dormant;

          (b)  Receives no revenue;

          (c)  Has no employees; and

          (d)  Owns no property.

     (3)  If a governmental entity exempt from liability by subsection (2) becomes active, receives income, hires employees or acquires any property, such governmental entity shall no longer be exempt from liability as provided in subsection (2) and shall be subject to the provisions of this chapter.

     SECTION 24.  The Attorney General of the State of Mississippi shall submit this act, immediately upon approval by the Governor, or upon approval by the Legislature subsequent to a veto, to the Attorney General of the United States or to the United States District Court for the District of Columbia in accordance with the provisions of the Voting Rights Act of 1965, as amended and extended.

     SECTION 25.  This act shall take effect and be in force from and after the date it is effectuated under Section 5 of the Voting Rights Act of 1965, as amended and extended.